Loading...
1999-018 To Authorize the Execution of a Subdivision Agreement (Maplehill Estates) , I .,,-; --1i, "'","" THE CORPORATION OF THE TOWNSHIP OF ORO-MEDONTE BY-LAW NO. 99-18 Being a By-Law to Authorize the Execution of a Subdivision Agreement (Maplehill Estates) WHEREAS draft approval for a registered plan of Subdivision on Part Lot 37, Concession 1, East of the Penetanguishene Road, Reference Plan, 51R-23604, Township of Oro-Medonte (formerly Township of Oro), County of Simcoe, known as the Maplehill Estates Subdivision has been obtained from the Ministry of Municipal Affairs and Housing; AND WHEREAS pursuant to Section 51(26) of The Planning Act, 1990, as amended, it is deemed desirable for the Township to enter into Subdivision Agreement with the Owner and have the Subdivision Agreement registered against the title of the said lands; NOW THEREFORE the Council for The Corporation of the Township of Oro-Medonte hereby enacts as follows: 1. That the Mayor and Clerk are hereby authorized to execute on behalf of The Corporation of the Township of Oro-Medonte a Subdivision Agreement, a copy of which is attached hereto and forms part of this By-law as Appendix "A". 2. That the Municipality shall be entitled to enforce the provisions of the Subdivision Agreement against the owners and any and all subsequent owners of the land. READ a first and second time this 17th day of February,1999. READ a third time and finally passed this 17th day of February, 1999. THE CORPORATION OF THE TOWNSHIP OF ORO-MEDONTE ~d- JS~ Mayor, Ian Bear, 1L Y~,t~ /1.. '~ Clerk, Lynda Aiken r " .. ., 4 SUBDIVISION AGREEMENT - between - 1091402 ONTARIO LTD. - and - Appendix "A" THE CORPORATION OF THE TOWNSHIP OF ORO-MEDONTE . MMA 43- T -90055 January 1999 - and - THE MORTGAGEES DESCRIPTION OF LANDS PART LOT 37, CONCESSION 1 EAST OF THE PENET ANGUISHENE ROAD RP 51R-23604 TOWNSHIP OF ORO-MEDONTE COUNTY OF SIMCOE 4 . ...... .' ' .. Part 1 Part 2 Part 3 Part 4 Part 5 Part 6 Part 7 Part 8 Part 9 Part 10 Schedule" A" - Schedule "B" - Schedule "C" - Schedule "D" - Schedule "E" - Schedule "F" - Schedule "G" - Schedule "H" - Schedule "I" - Schedule "J" - Schedule "K" - Schedule "L" - Schedule "MOO TOWNSHIP OF ORO-MEDONTE SUBDIVISION AGREEMENT TABLE OF CONTENTS General Requirements Lands, Plans and Representatives Requirements Prior to Execution of the Agreement Pre-Construction Requirements Financial Requirements Staging or Phasing Construction Requirements Building Permits and Occupancy Maintenance and Acceptance Default Provisions SCHEDULES Description of Lands Being Subdivided Plan of Subdivision Works to be Constructed Itemized Estimate of Cost of Construction of Each Part of the Works List of Lots Unsuitable for Building Purposes and/or Requiring Special Attention Services- In-Lieu Agreement Cash Deposits, Development Charges and Security Deeds and Easements to be Conveyed Parkland Declaration of Progress and Completion General Location and Lot Grading Plans Standard Township Letter of Credit Shared Road Access 2 p' 4 . .. TOWNSHIP OF ORO-MEDONTE TIDS AGREEMENT made as of the , 1999. day of BETWEEN: 1091402 ONTARIO LTD. (hereinafter called the "Developer") OF THE FIRST PART AND THE CORPORATION OF THE TOWNSHIP OF ORO-MEDONTE (hereinafter called the "Township") OF THE SECOND PART AND (hereinafter called the "Mortgagee") OF THE THIRD PART WHEREAS the lands affected by this Agreement are the lands described in Schedule "A" hereto annexed, and are also shown on the Plan of Subdivision attached to and forming part of this Agreement as Schedule "B" and collectively are herein referred to as the "said lands"; AND WHEREAS a Draft Plan with Conditions (43-T-90055) has been issued for the proposed subdivision, which requires that the Developer must satisfy all the requirements financial and otherwise of the Township, including the provisions of certain Municipal Services; NOW THEREFORE TIDS AGREEMENT WITNESSETH that in consideration of the premises and for other good and valuable consideration and the sum of Two Dollars ($2.00) of lawful money of Canada now paid by the Township to the Developer (the receipt whereof is hereby acknowledged), THE DEVELOPER AND THE TOWNSIDP HEREBY COVENANT AND AGREE WITH ONE ANOTHER AS FOLLOWS: 3 ". " . .... \ . . ~ 1.1. PART -1 GENERAL REQUIREMENTS DEVELOPER'S CONSULTING ENGINEERS The Developer shall employ engineers registered and in good standing with the Association of Professional Engineers of Ontario: 1.1.1 to prepare designs in accordance with the Township of Oro-Medonte Engineering Standards and Drawings (dated June 1997); 1.1.2 to prepare and furnish all required drawings and specifications; 1.1. 3 to prepare the necessary contract( s) and provide contract administration; 1.1.4 to obtain the necessary approvals in conjunction with the Township, from the Ministry of the Environment and Energy, the Nottawasaga Valley Conservation Authority, the Simcoe County District Health Unit and utility companies or as a result of legislative or procedural change, the ministries shall be deemed to be the Ministry of Municipal Affairs and Housing, as well as the Council of the Township of Oro-Medonte or the Chief Building Official.. This will also pertain to Sections 2.3.3,3.1.11,8.1 and 8.2 (a). 1.1.5 to act as the Developer's representative in all matters pertaining to the subdivision; 1.1.6 to provide co-ordination in scheduling to comply with the timing provisions of this Agreement and the requirements of the Township Engineer, for all the work specified in this Agreement; 1.1.7 to provide supervision during construction of all the services; 1.1.8 to ensure that the work involved in construction of the services IS carried out by construction methods conforming to acceptable engineering practice; 1.1.9 to maintain records of construction which shall be available for inspection or copy by the Township; 1.1.10 to prepare final "as constructed" mylar drawings which will include the following with regard to provision of a digital Plan of Subdivision: "completed digital Plan of Subdivisions must be in AutoCAD 12 drawing format or DXF and be delivered on a 1.44 MB floppy diskette. Two copies of each Plan of Subdivision are required on separate diskettes. Each diskette must be labelled identifying the legal property description, developer's name, file name, and date delivered. PKZIP Release 2.04G may be used to perform file compression if required. It is the Developer's responsibility to ensure that all drawing changes occumng throughout the approvals process are incorporated into the digital submission. All line data depicting property boundaries must be mathematically closed to forn1 polygons. The lines which describe the boundary of all properties created within the Plan of Subdivision will be isolated on a unique layer/level. In certain cases, some of the line segments will coincide with the location of concession lot lines, registered plan data, open roads, rivers, and lakes. The file may contain duplicate line work, however, when all other layers are turned off, the PLAN OF SUB layer/level will outline the property boundaries in the form of enclosed polygons. LA YERlLEVEL PLAN OF SUB LINE TYPE CONTINUOUS COLOUR YELLOW (2) 4 , ~ .... ,. e , .. The text which describe the property lot numbers for the Plan of Subdivision will be isolated on a unique layer/level. The lot number will be inserted as descriptive text. LA YERJLEVEL PL LTTEXT FONT MONOTEXT COLOUR YELLOW (2) The digital files should contain enough site data as to allow for horizontal and vertical positioning within the existing base mapping. A minimum of two road intersections located outside the Plan of Subdivision must be shown in the drawing. It is not necessary that the digital data be in Universal Transverse Mercator (UTM) co- ordinates since the registration process will automatically convert any unit grid to the Ontario Base Mapping UTM co-ordinate system"; 1.1.11 to furnish the Township with a certificate with respect to each lot or building block for which a Building Pennit application is made, certifying that the proposed construction is in confonnity with the General Location and Lot Grading plan or with an approved variation; (Note: That a professional engineer could also be retained to provide the aforementioned and any cost incurred by the Township will be the responsibility of the Developer or individual lot owner); 1.1.12 to prepare and provide the Township, for each lot or block within the plan, a certificate of final grade elevation, indicating that the property has been developed in conformity with the General Location and Lot Grading plan or with an approved variation (Note that a professional engineer could also be retained to provide the aforementioned and any costs incurred by the Township will be the responsibility of the Developer or individual lot owner) ; NOTE: In the case of lots built on after the sale or transfer by the Developer, the Township reserves the right to request a similar certificate as required under 1.1.11 and 1.1.12, but it may be provided by a Professional Engineer, other than the Developer's Consulting Engineer. If the Township has their Engineer prepare the Certificate, the cost of the work will be deducted from the final occupancy and lot grading deposit and will become the responsibility of the individual lot owner. 1.2 LEGAL NOTICE TO DEVELOPER Any notice required to be given hereunder may be given by registered mail addressed to the Developer at his principal place of business and shall be effective as of the date of the deposit thereof in the post office, as follows: 1091402 ONTARIO LTD. 24 TANNERY COURT RlCHMONDHILL, ONTARIO L4C 7V 4 In which case, notice shall be effective as of the time and date of successful transmission thereof. The Developer shall be responsible for notifying the Township Clerk in writing of any change(s) in his principal place of business. 1.3 REGISTRATION The Developer consents to the registration of the Subdivision Agreement by the Township and at the sole discretion of the Township upon the title of the lands, the registration expenses shall be included as a legal expense to the Developer.. 1.4 VOIDING AGREEMENT In the event that the Plan is not registered within one year from the date of signing this Agreement, the Township may at its option, declare this Agreement to be null and void. 5 ... " 1.5 MORTGAGEE BECOMING DEVELOPER - The mortgagee(s) hereby agrees that in the event of him/they becoming the Developer(s) of the lands under his/their mortgage by way of foreclosure, purchase or otherwise, either beneficially or in trust, then the mortgage( s) shall be deemed to be postponed to this Agreement and any lands registered in the name of the Township shall be free of the mortgage(s), and the mortgagee(s) agrees to register a discharge of the mortgage(s) on those lands if called upon by the Township, to do so, and he/they shall be subject to the terms of the Agreement as though he/they had executed this Agreement in the capacity of the Developer. 1.6 ASSIGNMENT OR TRANSFER OF MORTGAGE The mortgagee(s) agrees that in the event of him assigning or transferring the mortgage(s) on the lands, the assignment(s) or transfer(s) shall be subject to the terms hereof, in the same manner as if the assignee or transferrer has executed this Agreement. 1.7 LANDS FOR MUNICIPAL PURPOSES The Developer agrees to grant good title in fee simple free and clear from all encumbrances unto the Township, lands for municipal purposes other than roads, which shall be mutually agreed upon by the Developer and the Township or to make a cash payment in lieu thereof, as provided by the Planning Act and required by the Ministry of Municipal Affairs and Housing. The Developer also agrees to certify good title to lands by the Developer's Solicitor. The deeds for the said lands are to be approved by the Township's Solicitor and thereafter, forthwith, registered and deposited with the Township Clerk. The cost for preparation and registration of the said deeds shall be paid by the Developer. The Developer shall provide to the Township's solicitor certification of good title, free and clear from all encumbrances. 1.8 EASEMENTS The Developer agrees to grant at his expense all such easements and rights-of-ways as may be required for the installation and supply of services to the subdivision and to deed lands to the Township, as set out in Schedule "G". The Developer also agrees to certify good title to easements and right-of-ways by the Developer's Solicitor. Prior to executing this agreement, all known easements shall be filed with the Township in a form approved by the Township's Solicitor. A list of easements and rights-of-way shall be set out in Schedule "G" of this Agreement. 1.9 ONTARIO HYDRO AND BELL CANADA Prior to the Township releasing this proposed Plan for registration, the Developer shall provide the Township with a letter from Ontario Hydro and from Bell Canada, stating that the Developer has entered into a satisfactory agreement with them with respect to the costs of installing underground wiring and financial contributions in this regard. The cost of any relocations or revisions to Ontario Hydro and/or Bell Canada which are necessary to accommodate this subdivision shall be borne by the Developer. 1.10 SIMCOE COUNTY BOARDS OF EDUCATION WARNING The Developer agrees to advise all prospective purchasers that enrolment within the designated public school sites in the community is not guaranteed and that pupils may be accommodated in temporary facilities and/or be directed to facilities outside of the area. This clause is to be placed in any agreement of purchase and sale entered into with respect to any lots on this Plan of Subdivision. The clause should remain in perpetuity as lots may not be sold or built upon for some time. 1.11 CANADA POST , The Developer agrees to construct a site to the specifications and standards of Canada Post and the Township, as required for the construction of mail boxes by Canada Post. 6 e - ..... . \' 1.12 MINISTRY OF THE ENVIRONMENT AND ENERGY The Developer and each individual lot owner, agrees to comply with the requirements and recommendations of the hydrogeologist's report prepared by Ian Wilson Associates Ltd., dated March 22, 1992; In addition, the Developer shall notify each prospective purchaser of a lot(s) that: (a) Wells should only be constructed into the water supplies that had their quality confirmed through testing. (b) Elevated iron concentrations are possible and may require treatment for aesthetic reasons. 1.13 WARNING TO PROSPECTIVE LOT DEVELOPERS The Developer shall provide copies of Clauses, k), 1) & Note of 1.1,1.10,1.11,1.12,7.3,7.9, 7.16,8.1,8.2,8.3,8.4,8.5 and 9.8 to each prospective purchaser of a lot(s). 1.14 SAVE HARMLESS The Developer covenants and agrees with the Township, on behalf of itself, its successors and assigns, to indemnify and save harmless the Township, its servants and agents from and against any and all actions, suits, claims and demands whatsoever, which may arise either directly or indirectly by reason of any work performed by the provisions of this Agreement. The Developer further covenants and agrees to release and forever discharge the Township from and against all claims, demands, causes of actions, of every nature and type whatsoever that may arise either as a result of the failure of the Township to carry out any of its obligations under this Agreement, or, as a result of the Township performing any municipal work on the said lands or the adjacent properties which may damage or interfere with the works of the Developer, provided that such default, failure or neglect was not caused as a result of negligence on the part of the Township, its servants or agents. 1.15 ENUREMENT This agreement shall endure to the benefit of and be binding upon the parties and their heirs, executors, administrators, successors and assigns. 7 - a ... , / PART 2 THE LANDS. PLANS. AND REPRESENTATIONS 2.1 SCOPE OF AGREEMENT 2.2 DESCRIPTION OF LANDS - The lands affected by this Agreement are the lands described in Schedule "A" hereto. 2.3 PLAN REFERENCE - For the purpose of this Agreement, references are made to the Plan of Subdivision attached hereto as Schedule "B". Any further changes in the said Plan, or any changes in the Conditions of Draft Approval, issued by the Ministry of Municipal Affairs and Housing, may necessitate a change in the provisions of this Agreement. 2.4 CONFORMITY WITH AGREEMENT - The Developer covenants and agrees that no work shall be performed on the said lands except in conformity with: 2.4.1) the provisions of this Agreement, including the Schedules hereinafter referred to; 2.4.2) the Plans and Specifications submitted to and accepted by the Township as being within its design criteria including, without limiting the generality of the foregoing, the following: Drawing: No. Description G-1 to G-4 SWD-1 LG-1 to LG-3 P-1 to P-2 P-3 to P-4 P-5 to P-7 P-8 to P-9 P-10 P-ll P-12 SD-1 to SD-3 PND-1 PND-2 PND-3 PND-4 General Servicing Plan Storm Drainage Plan Lot Grading Plan Plan and Profile - Green Mountain Court Plan and Profile - Pineview Drive Plan and Profile - Northwood Court Plan and Profile - Red Pine Court Plan and Profile - Maplehill Drive Plan and Profile - Block 77 and 76 Plan and Profile - Woodland Crescent and Block 67 Standard Detail Sheet Extended Detention Facility Basin lOO-Block 78 Extended Detention Facility Basin 200-Block 73 Extended Detention Facility Basin 300-Block 79 Pond Section 2.4.3) All Plans and Specifications submitted to and accepted by: 2.4.3.1 2.4.3.2 2.4.3.3 2.4.3.4 The Ministry of the Environment and Energy (MOEE); Ontario Hydro; Simcoe County District Health Unit (Health Unit); Nottawasaga Valley Conservation Authority; 2.4.4) all applicable Township By-laws - including any applicable Site Plan Control By-laws; 2.4.5) all applicable Provincial and Federal Legislation. 2.5 RELIANCE UPON REPRESENTATIONS - The Developer acknowledges that: 2.5.1) it has made representation to the Township that it will complete all municipal and other works required herein, in accordance with the Plans filed and accepted by the Township and others, and; 2.5.2) the Township has entered into this Agreement in reliance upon those representations. 8 - . .... . / 2.6 SCHEDULES ATTACHED - The following schedules are attached to and form part of this Agreement: Schedule "A" Schedule "B" Schedule "C" Schedule "D" Description of Lands Being Subdivided Plan of Subdivision Works to be Constructed Itemized Estimate of Cost of Construction of Each, Part of the Works List of Lots Unsuitable for Building Purposes and/or Requiring Special Attention Cash Deposits, Development Charges & Securities Deeds and Easements to be Conveyed Parkland Declaration of Progress and Completion General Location and Lot Grading Plans, Standard Township Letter of Credit Schedule "E" Schedule "F" Schedule "G" Schedule "H" Schedule "I" Schedule "]" Schedule "K" 2.7 SUBDIVISION CHANGES There shall be no changes in the Schedules attached hereto, or in any Plan accepted by the Township or others, unless such proposed changes have been submitted to, and approved by, the Township and the Township Engineer. 9 e - .. , . PART-3 REQUIREMENTS PRIOR TO EXECUTION OF AGREEMENT 3.1 Prior to the execution of this Subdivision Agreement by the Township, the Developer shall: 3.1.1) Taxes - have paid all Township tax bills issued and outstanding against the said lands, 3.1.2) Deeds and Easements - have delivered to the Township all transfers/deeds, discharges and easements or other documents required by Schedule "G", as well as Certification from the Developer's Solicitor that the Transfer/Deeds and Easements shall provide the Township with good title, free and clear from all encumbrances, 3.1.3) Postponement Mortgage/Charge - file with the Township Solicitor, for his approval, a postponement of Mortgage/Charge document. 3.1.4) Cash Deposits, Development Charges & Security - have paid to the Township all cash deposits, development charges and security required by Schedules "D" & "F", 3.1.5) Construction/Engineering Plans & Sl'ecifications - have supplied to the Township those Plans and Specifications necessary to identify the construction/engineering aspects of the proposed development, and have received from the Township an acknowledgment of conformity with general design concepts of the Township, 3.1.6) Hvdro - have supplied to Ontario Hydro, and received their approval of, those plans necessary to identify the electrical distribution system, lighting requirements, and power supply to each lot or building or unit, as the case may be, and these are to be to the required Township standards which includes underground wiring, 3.1.7) Insurance Certificate - file with the Township Clerk an insurance certificate confirming those coverages specifically set out hereafter, 3.1.8) Consulting Engineer's Letter - ensure that each Consulting Engineer (who must be experienced in the field of municipal services) for the Developer, file with the Township, a letter confirming the terms of his retainer, and which letter shall be in draft format supplied by the Township, 3.1.9) Utilities and Canada Post Confirmation - arrange for Hydro, Bell Telephone, the Natural Gas Utility, Cable T.V. and Canada Post, to write a letter to the Township Clerk confirming: 3.1.9.1) that they have been informed of the project, and have seen the development plans, 3.1.9.2) that satisfactory arrangements have been made with them for servicing the subdivision without expense or obligation on the part ofthe Township. 3.1.9.3) easement requirements, if any, 3.1.10) Land Ownership- be the registered owner in fee simple of the lands described in Schedule "A", and that there will be no encumbrances registered against the said lands. 3 .1.11) Ministry etc. Approvals - obtain and file with the Township confirmation approvals from the following: 3.1.11.1) 3.1.11.2) 3.1.11.3) 3.1.11.4) MOEE; Ontario Hydro; Health Unit; Nottawasaga Valley Conservation Authority; 10 - .. .... . # 3.1.12) Lot Sizes - file with the Township a certificate from an Ontario Land Surveyor confirming that the frontage and area of each lot meets the minimum requirements of the Township zoning By-law, 3.1.13) Community Mail Boxes - file with the Township a Plan showing the location of, and access to, community mail boxes, 3.1.14) Mvlars - provide for registration, mylars of all Plans incorporated into this Agreement as Schedules, 3.1.15) Fire Chief Approval -obtain an Approval from the Fire Chief of the Township confirming and approving of the proposed plans for fire protection, and specifying any hydrants, or other equipment or appurtenances required. 11 ..... . PART - 4 PRE-CONSTRUCTION REQUIREMENTS 4.1 Prior to Starting Construction of the Subdivision Works, the Developer shall: 4.1.1 Plan Registration - Obtain final approval of the Plan from the Ministry of Municipal Affairs and Housing and obtain registration of the Plan; 4.1.2 Approval Of Plans The Developer and the Engineers employed by him shall have the plans and specifications for the works approved by the Township Engineer prior to construction and the originals must be stamped as accepted by the Township Engineer. Submit and obtain the Township Engineer's approval of the following, all to be in accordance with the Township's approved Engineering Standards; i) the drainage plan; ii) the lot grading plan; iii) the service layout plan for Hydro, Telephone and Gas; iv) the road and sewer plans and profiles. 4.1.3 Certificate Of Approval Submit to the Township, the Ministry ofthe Environment and Energy's Certificate of Approval for Storm Sewer Works and detention facilities; 4.1.4 Contractor The said services shall be installed by a contractor or contractors retained by the Developer and approved in writing by the Township Engineer. The Township and Township Engineer are to be provided with the names and phone numbers of personnel responsible for the Works, including emergency phone numbers. 4.1.5 Scheduling Of Works Prior to the start of construction, the Developer shall supply, for the Township Engineer's, approval, of a Schedule of Works, setting out the order in which he considers the various sections of the works within the Plan will be built. The Township Engineer may amend this Schedule and the Developer shall construct, install or perform the works as the Township Engineer from time to time may direct. In any event, the Schedule, or amended Schedule, as the case may be, shall conform to the requirements of Clause 4.1.8. 4.1.6 Erosion And Siltation Control The Developer must take all necessary precautions to prevent erosion and sedimentation of sewers, ditches, culverts, slopes, etc. both within the Subdivision and downstream prior to and during construction and upon completion of servicing of the Subdivision. Failing adequate precautions being taken, the Developer sha4l be responsible for correcting any damage and paying all maintenance costs resulting therefrom. ~ A Storm Drainage and Siltation Control Plan shall be prepared by the Developer's Engineer for approval by the Township Engineer and the Nottawasaga Valley Conservation Authority. Prior to any grading or construction commencing on the site or final approval and registration of Subdivision, the Developer's Engineer shall submit the plan for approval by the Township Engineer and the Nottawasaga Valley Conservation Authority. The plan shall detail the means whereby erosion and siltation and their effects will be minimized on the site during and after the construction period. The Developer agrees to carry out or cause to be carried out the work approved in the Plan, and such work will be certified in writing by the Developer's Engineer and provided to the Township Engineer and the Nottawasaga Valley Conservation Authority. The Developer agrees to maintain all erosion and siltation control devices in good repair during construction. 12 . . .... '. . 4.1.7. S1m2 4.1.8 Signs at least 1.2 metres by 1.8 metres shall be provided and erected by the Developer at each entrance to the subdivision, at a location approved by the Township Engineer, and the signs shall read as follows: "Roads Not Assumed by Township - Use at Your Own Risk". The signs shall be painted either orange or yellow with black lettering. These signs shall be installed prior to the commencement of construction and be removed after the issuance of the Certificate of Substantial Completion and Acceptance (Above ground Services). Notification Of Commencement And Completion The Developer shall not commence the construction of any of the works until the Developer has provided forty-eight (48) hours written notice to the Township Engineer, of his intent to commence work. The Developer shall complete the works expeditiously and continuously, and all underground services shall be installed within one year of the day of registration of this Agreement, and all above-ground services shall be installed in accordance with the Declaration of Progress and Completion, as required under Clause 7.11 of this Agreement, but no longer than two years from the date of registration of this Agreement, unless extended by the Township Engineer. Should for any reason there be a cessation or interruption of construction, the Developer shall provide forty-eight (48) hours written notice to the Township Engineer before work is resumed. If the Municipal Services to be constructed by the Developer under this Agreement are not completed and accepted by the Township within the above time frame, the Township may either; (a) give notice to the Developer to stop work on the said Municipal Services and to provide that no further work shall be done with respect to such services, until an Amending Agreement, incorporating the Standards, Specifications and financial requirements of the Township, in effect as of that date, is executed by all parties; or (b) give notice to the Developer to stop work on the Municipal Services and inform the Developer that the Township proposes to realize on its security and proceed with the completion of construction in accordance with the provisions of the Plans filed with the Township. 4.2 BREACH OF AGREEMENT If the Developer commences or causes construction of the works prior to satisfying the requirement of this Agreement, it shall be subject to the penalties identified in Part 10. 13 ... . .. PART-5 FINANCIAL REQUIREMENTS 5.1 DEVELOPER'S EXPENSE . Every provision of this Agreement by which the Developer is obligated in any way shall be deemed to include the words "at the expense of the Developer" unless specifically stated otherwise. 5.2. TOWNSHIP'S LEGAL, PLANNING AND ENGINEERING COSTS The Developer agrees to pay to the Township, the cost of the Township's lawyer and planner for all costs involved in processing the subdivision and of the Township's Engineer for checking of plans and specifications and inspection on behalf of the Township. The inspection by the Township will depend on the type of construction and the amount provided will be deemed necessary by the Township. In this regard, the Developer agrees to pay to the Township, the sum of Nine Thousand Dollars ($9,000.00) upon submitting a Plan to the Township for consideration to be applied to account of such costs. As accounts are received from the Township planner, lawyer, and engineer, they will be paid by the Township and then submitted to the Developer for reimbursement within thirty (30) days, so that the initial deposit will again be built up to enable the Township to pay the next accounts as they are received. In the event that the deposit is drawn down to a level of Five Thousand Dollars ($5,000.00) or less, and the Developer does not pay the accounts within thirty (30) days, it is hereby understood and agreed that the Developer would be in default of this Agreement and the Township may, without notice, invoke default provisions as set out in this Agreement. 5.3 DEVELOPER'S LIABILITIES Until the Township has issued the Certificate of Maintenance and Final Acceptance for the works, the Developer shall indemnify the Township against all actions, causes of action, suits, claims and demands whatsoever which may arise either directly or indirectly by reason of the Developer undertaking the Plan and the Township shall not be deemed to be the Developer. 5.4 UTILITY COSTS AND CHARGES The Developer shall deal directly with the Hydro Commission and all other Utility commissions and companies. He or his Consulting Engineer, shall obtain all approvals and permits and pay all fees and utility charges directly to the Utility until the Certificate of Maintenance and Final Acceptance (Underground Services) is issued. If an additional hydro service is required for Township purposes, the Developer shall include the cost of installation and maintenance of the service. 5.5 DEVELOPMENT CHARGES, ACT LEVIES AND DRAINAGE AND LOCAL IMPROVEMENT CHARGES a) The Developer, as a capital contribution towards other Township services, will pay to the Township, in addition to all other monies required to be paid by the Developer under this Agreement, and subject to the Service-in-lieu Agreement, attached hereto as Schedule "F", the Development Charges Act Levy, in an amount required by the Township's Development Charges By-Law, on the date the payment is received by the Township at the Municipal Office. The Development Charges Act Levy in place at the time of the execution of this Agreement is Two Thousand Nine hundred and Sixtv, Dollars ($2,960.00) per dwelling unit. . An amount equal to or greater than the hard services portion of the total Development Charges Act Levies for all the lots, must be paid at the time of execution of the Subdivision Agreement. If construction of the services occurs in particular stages or phases, as approved by the Township, the hard services portion of the total Development Charges Act Levies for all lots contained within the first stage or phase must be paid at the time of execution of the Subdivision Agreement. Payment of the hard services portion of the total Development Charges Act Levies for lots contained within subsequent stages or phases must be paid at the time of approval to proceed with construction of each subsequent stage or phase. Prior to issuance of a building permit, the remainder of the Development Charges Act Levy is to be paid on a per lot basis, until levies have been paid for all lots. 14 . . .... ~ Note: b) The Developer agrees to pay for all arrears of taxes or other Township or provincial charges, taxes or levies outstanding against the property herein described before the approval of the said plan is obtained. The Developer further undertakes and agrees to pay taxes levied on the said lands, on the basis and in accordance with assessment and collector's roll entries until such time as the lands herein being subdivided have been assessed and entered on the Collector's Roll according to the Registered Plan. c) Before the plan is approved, the Developer agrees to commute and pay the Township's share of any charges made under the Drainage Act 1975 and Local Improvements at present serving this property and assessed against it. These charges are set out in Schedule "F" of this Agreement. In addition to the Municipal Development Charges, the lots may be subject to County Development Charges, Education Development Charges and applicable Development Charges of any Public Utility Commission. 5.6 SECURITIES Prior to signing the Subdivision Agreement, the Developer will deposit with the Treasurer of the Township to cover the faithful performance of the contract for the installation of the said services and the payment of all obligations arising thereunder the following securities: a) Cash in the amount of one-hundred percent (100%) of the estimated cost of the said work as approved by the Township Engineer and Township Council, or: b) An irrevocable Letter of Credit from a chartered Bank, issued in accordance with the requirements of Schedule "K" with an automatic renewal clause, in the amount of one hundred percent (100%) of the estimated costs of the said works and the Occupancy/Lot Grading Deposit, as set out in Schedule "0" and as approved by the Township Engineer. The Letter of Credit shall be for a minimum guaranteed period of one (I) year or such time as the Township decides and shall be renewed automatically, as necessary, three (3) months prior to expiration. Unless the Letter of Credit is renewed as noted above, the Township shall have the absolute right to refuse to issue building permits and to prohibit occupancy of homes, whether partially or fully completed, from the said date, three (3) months prior to the expiration of the Letter of Credit, or the Township may cash the Letter of Credit until a satisfactory Letter( s) of Credit is received by the Township. c) Notwithstanding the provisions of subparagraphs (a) and (b) above, the estimated cost of the Works as set out in Schedule "0" will be reviewed and updated by the Township Engineer on each anniversary of the date of execution of this Agreement. In the event of an increase, the Developer shall provide additional security as required by the Township Engineer within thirty (30) days of notice by registered mail from the Township Engineer. In the event that the Developer fails to deliver to the Township the additional security as required by the Township Engineer, it is hereby understood and agreed that the Developer be deemed to be in default of this Agreement and the Township may, without notice, invoke default provisions as set out in this Agreement. The Township reserves the right to accept or reject any of these alternative methods of providing securities. Prior to depositing the securities, the Developer's Engineer shall submit an estimate of the cost of the works to the Township Engineer for approval. When the cost estimate has been approved, it will be set out in Schedule "0" of this Agreement and will become the basis for the limits of the securities. In the event that the Tendered Contract price for the Township Services set out in Schedule "0" is greater by 10% than the estimates in the said Schedules, then the security provided for above shall be increased to an amount equal to the Tendered Contract price. d) Application - Any Letter of Credit or security filed with the Township is based upon the estimated cost of completing the various matters prescribed by this Agreement. However, all Letters of Credit and Security received by the Township may be used as security for any item or any other matter which under the tenns of this Agreement is the responsibility of the Developer, including without limiting the generality of the foregoing, payment of engineering, legal, planning, Development Charge By-Law obligations, or other costs incurred by the Township which are the responsibility of the Developer under the terms of this Subdivision Agreement, as well as Development Charges and costs to acquire lands or interest therein. 15 . . ~ e) Default - If, in the event of default of the Developer under any of the provisions of this Agreement, it becomes necessary for the Township to realize on its security or deposits, then the Township (its servants, agents or sub-contractors) shall, if the Township so elects, have the right and privilege at all times to enter upon the said lands for the purpose of repairing or completing any work or services required to be completed by the Developer under this Agreement. t) Exceeding Cost Estimates - If the costs of completing such work or service, exceeds the amount of security held by the Township, such excess shall be paid by the Developer to the Township thirty (30) days after invoicing by the Township. All overdue accounts shall bear interest at the rate of 12% per annum. g) Save Harmless - The Developer on behalf of itself, its successors and assigns agrees to indemnifY and save harmless the Township trom and against any and all claims, suits, actions and demands whatsoever which may arise either directly or indirectly by reason of any work or service performed by the Township, its servants or sub-contractors in order to complete the work or services required to be completed under this Agreement, provided the subject matter of such action, suits, claims or demands was not caused intentionally or through gross negligence on the part of the Township, its servants or agents or sub-contractors. h) The Construction Lien Act - If the Township becomes obligated to make any payments, or pay any costs, under the provisions of Section 17(4) of the Construction Lien Act, R.S.O. 1990, c.C.30, this will constitute a default and entitle the Township to realize upon its security. i) Surplus Funds - In the event that the Township cashes a Letter of Credit to complete Township services or satisfY any obligations under this agreement, any surplus monies that remain after this work is completed shall, upon full compliance by the Developer with the terms of this Agreement, be returned to the issuing financial institution for transmission to that party that took out the original Letter of Credit. 5.7 DISCHARGE OF SECURITIES 5.8. 5.7.1 Estimated Cost of Works - After the completion of fifty percent (50%) of the services based on the total Estimated cost of Works in the subdivision or in an approved stage of the subdivision, and provided the Developer is in compliance with all aspects of the Subdivision Agreement, the Developer shall, as the work further proceeds to completion, have the privilege, on application to the Township and upon Certification of the Township Engineer, of obtaining reductions of the cash or Letter of Credit deposited for the installation of the services, in increments of not less than ten percent (10%). Upon application for reduction of the securities, the Developer's Engineer shall provide an estimate of the cost to complete the work. This amount when approved by the Township Engineer shall be retained along with twenty percent (20%) of the original estimate and the remainder released. A further ten percent (10%) of the original estimate will be released upon satisfactory assurance to the Township that there are no liens pursuant to the Construction Lien Act affecting lands conveyed or to be conveyed to the Township within the Plan of Subdivision, pursuant to the terms of this Subdivision Agreement. 5.7.2 Final Occupancy and Lot Grading Deposit - The Developer shall, as works proceed to complete the final grading of lots or building blocks, have the privilege, on application to the Township and upon issuance by the Developer's Consulting Engineer of a Certificate of fmal grade elevation, of obtaining reductions of the cash or Letter of Credit deposited for Final Occupancy and Lot Grading. An application for reduction of securities shall be for not less than five (5) lots and the reduction shall be an amount equal to one hundred percent (100%) of the Final Occupancy and Lot Grading deposit for the lots subject to the application. The Developer may, upon the approval of Township, transfer the Final Occupancy and Lot Grading deposit to the lot owner upon sale or transfer of each lot. ST ATUTORY DECLARATION OF ACCOUNTS PAID The Developer agrees that upon applying for a Discharge of Securities, or for a Certificate of Substantial Completion and Acceptance, or for a Certificate of Maintenance and Final Acceptance for the services within the subdivision, or upon applying for prior acceptance of the underground services, he shall supply the Township with a Statutory Declaration that all accounts for work and materials for said services have been paid and that the construction Lien Act has been complied with and that no liens thereunder have or can be registered except normal guarantee holdbacks and that there are or will be no claims for liens or otherwise in connection with such work done or materials supplied for or on behalf of the Developer in connection with the subdivision. 16 .-- ..... ~ 5.9 . 5.10. . PLEDGE OF TITLE TO LANDS The Developer hereby charges and pledges as security for all costs, charges, expenses or obligations of the Developer under the provisions of this Subdivision Agreement all of its right, title and interest in the said lands, and consents to the registration of this Subdivision Agreement against title to the said lands. The Developer further agrees that all costs, charges or expenses incurred by the Township in satisfYing the obligations of the Developer in the event of default of the Developer under the tenns of this Subdivision Agreement, together with any costs, charges or expenses incurred by the Township in enforcing the obligations of the Developer under this Agreement, shall be a fIrst charge or lien against the said lands in accordance with the provisions of Section 326 of the Municipal Act, R.S.O. 1990, c.MA5. INSURANCE CERTIFICATE AND POLICY 5.10.1 Policy of Insurance - The Developer shall lodge with the Township, on or prior to the execution of the Agreement, an insurance certifIcate with an Insurance Company satisfactory to the Township, (which said approval shall not be unreasonably withheld or delayed), and insuring for the joint benefit of the Developer and the Township, against any liability that may arise out of the construction or installation of any work to be performed pursuant to this Agreement and for a period of one (1) year after completion and acceptance of the Township Services to be constructed herein. 5.10.2 Comprehensive General Liability - Such policy shall carry limits of liability in the amount to be specified by the Township, but in no event shall it be less than Five Million Dollars ($5,000,000.00) inclusive comprehensive general liability and such policy shall contain: (a) a cross-liability clause; (b) product/completed operation coverage; (c) shall not have an exclusion pertaining to blasting, provided that any blasting required to be done shall be done by an independent contractor duly qualifIed to do such work; (d) shall include the following names as insureds: (i) THE CORPORATION OF THE TOWNSHIP OF ORO-MEDONTE 5.10.3 Notice of Cancellation - a provisions that the insurance company agrees to notifY the Township within fifteen (15) days in advance of any canc~llation or expiry of the said insurance policy. 5.1004 Certificate of Coverage - Any certificate of coverage filed with the Township Clerk shall specifically contain their confirmation that coverage includes (a), (b), (c), (d) and ( e) above are in effect. 5.10.5 ConfIrmation ofPr~mium Payment - The Developer shall, from time to time as required by the Township, provide confirmation that all premiums on such policy or policies insurance have been paid, and that the insurance is in full force and effect. The Developer shall see that a copy of the policy is filed with the Township. 5.10.6 Claim in Excess of Policy Limits - The issuance of such Policy ofInsurance shall not be construed as relieving the Developer from responsibility for other or larger claims, if any, and for which it may be held responsible. 17 . . .... . .. 6. I PART-6 STAGING OR PHASING STAGING OR PHASING The Township, in its sole discretion, may instruct the Developer to construct the services in particular stages or phases suitable to the Township, and the Developer must comply, on terms to be agreed to by the Township. If the Township does not so instruct, the Developer, before commencement of any work, may request the Township's permission to divide the area of the subdivision into convenient stages. If the work is thus staged, as approved by the Township, then in lieu of furnishing cash payment or Letter of Credit all as set out in Clause 5.6 for one hundred percent (100%) of the estimated costs, as approved by the Township Engineer, the Developer shall deposit security for part of the services the Township has approved. Before proceeding with an additional stage, the Developer shall obtain the written approval of the Township and no service will be permitted to be installed and no building permits issued until this approval has been received and additional securities deposited. When fifty (50%) of the lots of the subdivision or stages of the subdivision have been built upon and all the services have not been completed and approved by the Township Engineer, the Township reserves the right to refuse commencement of the next stage until all services have been installed and approved. In no event will further subdivisions of the Developer or stages of subdivisions of the Developer be approved if all services of the active stage approved by the Township Engineer have not been completed within a two (2) year period after registration of this Agreement. Notwithstanding, anything hereinafter set out, the Township shall not be obligated to assume the responsibility for and take over the subdivision services until at least fifty percent (50%) of the lots on the subdivision or stage of the subdivision have completed dwellings erected therein and Final Certificate of Occupancy has been issued. The Developer shall be responsible for the maintenance of the services in this case until the Township has assumed the responsibility of the services. 18 .... . PART - 7 CONSTRUCTION REQUIREMENTS 7.1 WORKS TO BE INSTALLED The works to be installed are set out in Schedule "C" to this Agreement. This schedule is to set out the works in general terms only and shall not be construed as covering all items in detail. . The works are to be designed and constructed in accordance with the current Engineering Standards adopted by By-law by the Township at the time of signing of the Subdivision Agreement. A copy of these standards is available at the Municipal Office. If at any time, and from time to time during the development of the subdivision, the Township Engineer is of the opinion that additional works are necessary to provide adequately any of the public services required by the Plan, the Developer shall construct, install or perform such additional works at the request of the Township Engineer. 7.2. CONSTRUCTION OF WORKS Following the registration of this Agreement, the Developer shall cause to be constructed all requisite works, in order to provide services to the lots and buildings blocks within the Phase. 7.3. PRESERVATION AND PLANTING OF TREES 7.3.1 The Developer must preserve all healthy trees within the limits of the subdivision where possible. If, in the opinion of the Township Engineer, indiscriminate removal of trees takes place within the limits of the Plan of Subdivision including road allowances, parkland, and individual lots, the Township shall have the option of having a stop work order on construction of the services and/or building on a particular lot where the removal is taking place. Work will not be allowed to proceed until the Township is satisfied that the practice will not continue and the Developer/Builder agrees to carry out remedial work requested by the Township. The Developer agrees to provide a copy of this clause to each and every prospective builder/ prospective purchaser. 7.3.2 The Developer shall plant two (2) 2.4 metre or taller hardwood trees of a minimum of 50mm calliper on each lot having less than three (3) trees in the front yard(s) if required by the Township. The type of trees must be satisfactory to the Township. 7.3.3 In addition, the Developer shall plant trees with the above specifications at I5-metre intervals around the perimeter of the park, in areas where there is not a sufficient growth of trees. 7.4 MOVEMENT OF FILL The Developer covenants and agrees that he shall not dump nor permit to be dumped any fill or debris on, nor shall he remove or permit to be removed any fill, topsoil, trees or shrubs from any public or municipal lands, without the written consent of the Township Engineer. 7.5 BLASTING Before any blasting is proceeded with by the Developer, the Developer shall obtain from the Township Engineer or Township Public Works Official, written permission, for carrying out the blasting operation, and shall obtain the blasting permit and show proof of insurance for all damage or claims for damage resulting from the blasting operation. The Developer in any event shall be responsible for any such claims. 7.6 ACCESS ROADS . All access roads must be maintained by the Developer in good repair acceptable to the Township Engineer and Township Public Works Official during the time of construction, including dust control and the removal of any mud or debris tracked from the subdivision, and no roadway outside the limits of the proposed subdivision may be closed without the written consent of the To:vnship Public Works Official. For the purpose of getting such consent, the Developer shall advIse the Township Public Works Official and the Township Clerk of the date and time they wish to close a roadway. The Township reserves the right to limit or prohibit the use of any existing access road by the Developer. 19 ., " . . 7.7 DAMAGE TO EXISTING PLANT The Developer shall repair any damages caused to an existing road, Road Allowance or existing structure or plant located on the Road Allowance as a result of the subdivision development and shall pay for any costs involved in the relocation of existing services, such as hydrants, telephone poles, etc., which may become necessary because of the development of the subdivision. In this regard, the Developer's Engineer shall arrange for an inspection with the Township Public Works Official and Township Engineer for the purpose of compiling an inventory of existing conditions prior to work on the subdivision. Otherwise, the Township Public Works Official's assessment of conditions prior to construction will be final. 7.8 DUST CONTROL Until the Certificate of Substantial Completion and Acceptance (Aboveground Works) has been issued, the Developer shall apply calcium to the roads within the Subdivision and/or utilized by construction traffic, in quantities sufficient to prevent any dust problem to traffic or home occupants, to the satisfaction of the Township Engineers. If the Developer has not taken remedial action within twenty-four (24) hours of receiving a written notification (via facsimile) from the Township's Engineer, regarding a dust control problem, then the Township's Engineer, at their sole discretion, shall employ outside forces to implement, at the Developer's expense, a suitable measure of dust control. 7.9 CONSTRUCTION REFUSE All construction refuse, garbage and debris from the subdivision must be disposed of in an orderly and sanitary fashion by the Developer, off the site of the subdivision, at a licensed landfill site. The Township is not responsible for the removal or disposal of refuse, garbage and debris. Open air burning is not permitted by the Township. The Developer agrees to deliver a copy of this Clause to each and every builder obtaining a building permit for any lot or part of a lot on the said Plan of Subdivision. 7.10 INSPECTION OF CONSTRUCTION OF SERVICES During construction of the services, the Township may inspect the work in hand at such times and with such duration and frequency as the nature of the type of construction may dictate. Subject to the obligations of the Township Engineer to protect the interests of the Township through such inspections, every effort will be made to keep duplication of engineering services on site to a minimum. If during such inspections, the Township Engineer perceives that construction, whether by method or otherwise, constitutes an immediate danger to life or property, or construction does not conform to acceptable practice in order to meet the requirements for services, he will have the authority to cease construction operations by verbal notice to the contractor and/or the Developer's Engineer, such notice to be confirmed in writing as soon as possible, thereafter. A copy of this Clause shall be delivered by the Developer to each and every contractor engaged in construction of services for the Subdivision. 7.11 DECLARATION OF PROGRESS AND COMPLETION 7.11.1 Prior to the approval of the underground services, the Developer shall provide the Township Engineer with an undertaking for the completion dates of all remaining works required by this Agreement and in a form similar to that attached to this Agreement as Schedule "I", the Declaration of Progress and Completion for approval of the Township Engineer. The Township reserves the right to alter the completion dates as it sees fit and the Developer agrees to complete the services. 7.11.2 It is understood and agreed that should the Developer fail to construct the remaining services, as stipulated, and by such dates as provided in the Declaration, th~ Developer shall pay to the Township, as predetermined, liquidated damages, the sum of FIfty Dollars ($50.00) for each and every day the said services are behind schedule of construction, and NO FURTHER BUILDING PERMITS SHALL BE ISSUED. 20 .... 7.12 e 7.13. PROGRESS OF WORKS After the completion of the underground services, the Developer shall complete the Declaration of Progress and Completion for the approval of the Township Engineer and from that date the said Declaration shall apply and take precedence over Clause 4.1.5. Prior to signing the Declaration of Progress and Completion, the Developer shall install all works in accordance with the Schedule of Works or as directed by the Township Engineer. Ifhe fails to adhere to the scheduling provisions outlined in the Schedule of Works or the Declaration, or having commenced to install the aforesaid works, fails or neglects to proceed with reasonable speed, or in the event that the aforesaid works are not being installed in the manner required by the Township Engineer, then upon the Township Engineer giving seven (7) days written notice by prepaid registered mail to the Developer, the Township Engineer may without further notice enter upon the said land and proceed to supply all materials and to do all necessary works in connection with the installation of the said works, including the repair or reconstruction of faulty work and the replacement of materials not in accordance with the specifications, and to charge the costs thereof together with an engineering fee of ten percent (10%) of the cost of such materials and works to the Developer who shall forthwith pay the same upon demand. If the Developer fails to pay the Township within thirty (30) days of the date on the bill, the money owing may be deducted from the cash deposit or Letters of Credit. It is understood and agreed between the parties hereto that such entry upon the land shall be as agent for the Developer, and shall not be deemed for any purpose whatsoever, as an acceptance or assumption of the said works by the Township. The Township, in addition to all other remedies it may have, may refuse to issue building permits until such works are completely installed in accordance with the requirements of the Township Engineer. It is agreed that a copy of this clause be delivered by the Developer to each and every builder obtaining a building permit for any lot or part of a lot on the said plan. SUBST ANTIAL COMPLETION OF UNDERGROUND SERVICES It is intended that the hydro and street lighting, sewer system and detention pond will be constructed, inspected and approved prior to the completion of the other Works. Building permits will not be issued until the Township Engineer has given the Certificate of Substantial Completion and Acceptance (Underground Services). The two (2) year maintenance period for the underground services will commence when this Certificate is issued. During the maintenance period, the Developer shall be responsible for the normal operation and maintenance, and all repairs for the services noted in the Certificate. If, during the two year maintenance period, the Developer fails to carry out rectification and repair work as requested by the Township, then the Township may carry out the work and be reimbursed, the cost of the work from the Developer's securities, as set out under Clause 9.3. Notwithstanding, anything hereinafter set out, the Township shall not be obligated to assume the responsibility for and take over the subdivision services until fifty percent (50%) of the lots on the subdivision or stage of the subdivision have completed dwellings erected therein and Final Certificate of Occupancy has been issued. The Developer shall be responsible for the normal operation, maintenance, and all repairs of the services, in this case, until the Township has assumed the responsibility of the services. 7.14. EMERGENCY REPAIRS Employees or agents of the Township may enter onto the Lands at any time or from time to time for the purpose of making emergency repairs to any of the works. Such entry and repairing shall not be deemed an acceptance of the works by the Township or any assumption by the Township of any liability in connection therewith or a release of the Developer from any of his obligations under this Agreement. 7.15 USE OF WORKS BY TOWNSHIP: e The Developer agrees that: I. The works may be used prior to acceptance, by the Township or other authorized persons for the purpose for which such works are designed. II. Such use shall not be deemed an acceptance of the works by the Township, and III. Such use shall not in any way relieve the Developer of his obligations in respect of the construction and maintenance of the works so used. 21 .~ . e 7.16 DRAINAGE AND LOT GRADING All lots and blocks within the Plan and all lands abutting the Plan shall be graded to drain in accordance with the overall grading plan to be prepared by the Developer's Engineer for approval by the Township Engineer and the Simcoe County District Health Unit. Some fill and regrading of lots may be necessary during or after building construction. The grading Plan shall show all existing and final grades on lot corners, as well as mid lot elevations, where deemed necessary by the Township Engineer. It is understood and agreed by the parties hereto that drainage of surface water on the lots and blocks on the plan is the sole responsibility of the respective lot owners once the required drainage works have been constructed by the Developer. The storm swales shall be landscaped and maintained by all subsequent lot owners. The purpose of the storm swales is to accommodate storm drainage waters from the subject lot and adjacent lands. No lot owner in the Subdivision shall encumber or impede storm drainage in any manner whatsoever. In the event that the Developer, or any subsequent lot owner , obstructs, impedes, or interferes with the storm drainage flow through any part of the storm swale, or interferes with the acceptance of water from any connecting swales, then the Township shall have the right, if it so elects, to enter upon the subject lands to rectify such problems so that the swales can serve their original purpose. Within the swale area, the Developer, and any subsequent lot owner, shall not, construct any works, remove or permit to be removed any soil from the said swale/easement, excavate, drill, install, erect or permit to be excavated, drilled, installed or erected in, over, upon, under or through the said swale/easement, any fence, well, foundation, pavement, building or other structure or other installation. The lot owner of any lot in the Subdivision upon which the Township elects to enter for the purpose of rectifying the said work, hereby agrees to indemnify and release the Township from and against all claims, demands, actions or causes of action whatsoever arising as a result of the Township or of its servants or agents entering upon the lands for the purpose of correcting drainage problems. The cost of such work will be for the account of the lot owner. Any invoices not paid within thirty (30) days after due date, shall be added to the tax roll and collected in a like manner as realty taxes, as per section 326 of the Municipal Act. The Developer agrees to deliver a copy of this Clause to each and every prospective purchaser and/or builder obtaining a building permit for any lot or part of a lot on the said Plan of Subdivision. The Developer's Engineer shall prepare a drainage plan for the site for the approval of the Township Engineer and the Simcoe County District Health Unit. Generally, the drainage facilities will consist of open ditches within the subdivision or storm sewers in certain locations to provide a satisfactory drainage outlet. The plan will show how water will be controlled on and off the site and will include swales and/or easements where necessary. 7.17 PARKLAND WORKS All parkland works indicated on the Park Development Plan are to be constructed in accordance with Section 14 - Park Requirements of the Township of Oro-Medonte Engineering Standards and Drawings. The parkland must be completed to the satisfaction of the Township prior to issuance of 25% of the total building permits allowed in the subdivision. 7.18 DEFINITIONS (i) For the purposes of this Subdivision Agreement: The term "Underground Services" shall mean the storm drainage works (including culverts, storm sewer and detention pond), underground electrical distribution system and streetlighting serving the Plan of Subdivision, as more particularly described in Schedule "C" to this Subdivision Agreement; 22 ..." . - (ii) The term "Certificate of Substantial Completion and Acceptance (Underground Services)" shall mean a Certificate issued by the Township upon the recommendation of the Township Engineer confirming that the Underground Services to be installed by the Developer under the provisions of this Subdivision Agreement, as more particularly identified in Schedule "C", have been substantially completed in accordance with plans and specifications reviewed and accepted by the Township Engineer. The issuance of a Certificate of Substantial Completion and Acceptance (Underground Services) shall not constitute an assumption of the Underground Services by the Township; (iii) The term "Certificate of Maintenance and Final Acceptance (Underground Services)" shall mean a Certificate issued by the Township upon the recommendation of the Township Engineer confirming that the Underground Services constructed by the Developer, in accordance with the terms of this Subdivision Agreement, and as more particularly identified in Schedule "C", have been satisfactorily completed and maintained by the Developer during the two-year (2) maintenance period, and issuance of the said Certificate shall constitute fmal acceptance and assumption of the Underground Services by the Township; (iv) The term "Aboveground Services" shall mean all municipal services to be constructed by the Developer pursuant to the terms of this Subdivision Agreement, as more particularly identified in Schedule "C", excluding Underground Services; (v) The term "Certificate of Substantial Completion and Acceptance (Aboveground Services)" shall mean a Certificate issued by the Township upon the recommendation of the Township Engineer confmning that the Aboveground Services to be installed by the Developer under the provisions of this Subdivision Agreement, as more particularly identified in Schedule "C", have been substantially completed, in accordance with plans and specifications reviewed and accepted by the Township Engineer. The issuance of a Certificate of Substantial Completion and Acceptance (Aboveground Services) shall constitute an assumption of the Aboveground Services by the Township for winter maintenance only; (vi) The term "Certificate of Maintenance and Final Acceptance (Aboveground Services)" shall mean a Certificate issued by the Township upon the recommendation ofthe Township Engineer confirming that the Aboveground Services constructed by the Developer in accordance with the terms of this Subdivision Agreement, and as more particularly identified in Schedule "C", have been satisfactorily completed and maintained by the Developer during the two-year (2) maintenance period, and issuance of the said Certificate shall constitute final acceptance and assumption of the Aboveground Services by the Township; (vii) The term "Certificate of Substantial Completion and Acceptance" means a Certificate of Substantial Completion and Acceptance (Underground Services) or a Certificate of Substantial Completion and Acceptance (Aboveground Services), as the provisions of this Subdivision Agreement require; (viii) The term "Certificate of Maintenance and Final Acceptance" means a Certificate of Maintenance and Final Acceptance (Underground Services) or a Certificate of Maintenance and Final Acceptance (Aboveground Services), as the provisions of this Subdivision Agreement requITe. 2~ . . , .. PART - 8 BUILDING PERMITS AND OCCUPANCY 8.1 SIMCOE COUNTY DISTRICT HEALTH UNIT APPROVAL The Developer further agrees that he or any person, persons, or Corporation claiming title through the Developer, will not apply for a Building Permit for any part or portion of the said lands or on any lot therein, and no Building Permit shall be issued until Simcoe County District Health Unit Approval has been received for the land in question. The Developer's Engineer shall prepare an overall lot development plan for approval by the Simcoe County District Health Unit and the Township Engineer as a further requirement to Clause 7.16. The plan shall include the following: (i) (ii) (iii) (iv) (v) (vi) (A) (C) (D) envelopes for the proposed house and any adjacent structures on each lot; an envelope showing the location, size and elevation of the subsurface sewage system on each lot and all pertinent engineering design criteria; existing and proposed grades of the disturbed area of lot after building, drainage and sewage works have been completed; existing and proposed grades on lot corners and mid lot elevation; location and type of proposed water well. The Developer agrees to advise all prospective lot Developers that a detailed site development plan for each lot may be required to be prepared by a Professional Engineer registered with the Association of Professional Engineers of Ontario, for approval by the Township Engineer, prior to the issuance of a Building Permit for each respective lot. Site development plans which conform to the overall lot development plan at an approved metric scale using metric dimensions and elevations, shall include the following: the location, dimensions and elevations of the proposed dwelling and any structures to be located on the lot, as well as any adjacent structures on the adjacent lot(s); (B) the location, size and elevation of the sewage system; for lots I, 5, 6, 8, 26, 46, 47 & 56, all engineering design criteria and standards pertaining thereto, shall be provided; the location and type of water well including the water service line to the dwelling; (E) (F) the existing and proposed grades of the disturbed area on the lot after building, drainage and sewage works have been completed; the location and grades of any proposed drainage swales; the professional engineer will be required to check the elevations of the footings of the buildings prior to further construction to ensure conformity with the approved plans noted above; (G) the professional engineer will be required, prior to the issuance of a Final Inspection Report, to certify to the Simcoe County District Health Unit, in writing, that the foregoing works have been carried out in accordance with the approved plans noted above. The Developer further agrees to construct all works required under Clause 7.16 and as shown on the approved General Location and Lot Grading Plans, Storm Drainage Area Plan and Erosion Control Plan, all prepared by Vincent & Associates, to the satisfaction of the Simcoe County District Health Unit and Township Engineer. The Developer further agrees to advise all prospective lot owners of the requirement, that it may be necessary for the sewage system to be installed prior to construction of the home subsequent to the issuance of a Certificate of Approval. 24 . . .. . ." 8.2 REQUIREMENTS FOR BUILDING PERMITS The approval of the plan by the Township or the acceptance by the Township of the works shall not be deemed to give any assurance that the municipal building permits, when applied for, wi!] be issued in respect of the lots or blocks shown on the plan. Notwithstanding the foregoing, no building permits wi!] be given and the Township may refuse any application until: (i) Simcoe County District Health Unit and Ministry of the Environment and Energy approvals have been obtained and submitted to the Township. Simcoe County District Health Unit requirements are set out in Clauses 7.16 and 8.1. (ii) The storm sewer systems have been installed, tested and approved by the Township Engineer and he has issued his Certificate of Substantial Completion and Acceptance (Underground Services). (iii) Plans for remaining underground services such as Bell Telephone, Hydro or Natural Gas have been approved. (iv) A "Builders" road consisting of the grading, curb and gutter or ditch shaping and full depth of Granular "B" sub-base has been constructed on the road providing access to the lot. (v) Approval of the Township Engineer has been obtained for the construction of any buildings to be erected on lots or blocks listed in Schedule "E" hereto. (vi) Signs denoting "Unassumed Roads" have been installed at the entrances to the subdivision in a location acceptable to the Township in accordance with Clause 4.1.7. (vii) A Certificate Letter and Lot Development Plan has been given by the Developer's Consulting Engineer or a Professional Engineer registered with the Association of Professional Engineers of Ontario, that the building to be erected on any lot or block within the plan, for which a Building Permit has been applied for, is in conformity with the General Location and Lot Grading Plans or has received the approval of the Township Engineer with respect to any variance to the grading plan. The individual Lot Development Plan must be approved by the Township Engineer prior to issuance of a Building Permit. (viii) All dead trees within the limit of the plan have been removed. (ix) Arrangements have been made and approved by the Township for Municipal Address System numbering as set out in Clause 8.4. (x) The parkland must be completed to the satisfaction of the Township, prior to the issuance of 25% of the total building permits allowed in the development. (xi) The Traffic and Street Name signs have been installed and approved by the Township Engineer. 8.3 LOTS UNSUITABLE FOR BUILDING OR LOTS REQUIRING SPECIAL ATTENTION Any lot which will require special attention, in order to be serviced, will be listed on Schedule "E" of this Agreement. Prior to the issuance of a building permit for any lot listed in Schedule "E", the Developer's Engineer must submit a letter to the Township Engineer outlining the measures to be taken to correct the problems on the lot. This proposal must be approved prior to applying for a building permit. 8.4 MUNICIPAL ADDRESS SYSTEM The Developer shall be responsible for obtaining the mun~cipal ad?ress system nu.mbers fo: .each and every lot from the Municipal Office. As a further req~Irement, m order to obtam a ~rovIsIonal Certificate of Occupancy , the Developer and/or butlde~, or lot owner, shall Install !he aforementioned number at a location approved by the TownshIp. The Developer agrees to provIde a copy of this clause to each and every builder or lot owner in advance of the sale of such lot( s). 25 \. , . 'c, . 8.5 REQUIREMENTS FOR OCCUPANCY 8.5.1 No buildings erected on the lots or blocks within the plan shall be occupied until a PROVISIONAL CERTIFICATE OF OCCUPANCY has been issued by the Township in accordance with the Township Building and Plumbing By-Law. PROVISIONAL CERTIFICATE OF OCCUPANCY means a permit issued to allow occupancy of a building. 8.5.2 A FINAL CERTIFICATE OF OCCUPANCY will not be issued until: (i) The roadway has received the granular roadbase materials full depth and the base course of asphalt provided asphalt is commercially available. (ii) The underground hydro, telephone lines, gas mains and street lights have been installed and approved by the Township Engineer. (iii) A Certificate Letter and individual Lot Development Plan has been given by the Developer's Consulting Engineer, or a Professional Engineer, registered with the Association of Professional Engineers of Ontario, that the building constructed, and the final grading of the lot or block is in conformity with the General Location and Lot Grading Plans or such variance therefrom has been approved by the Township Engineer. The final grading on the individual Lot Development Plan must be approved by the Township Engineer prior to issuance of a FINAL CERTIFICATE OF OCCUP ANCY. FINAL CERTIFICATE OF OCCUPANCY means a permit issued when all outstanding items on a Provisional Certificate of Occupancy including grading have been completed. (iv) Driveway culvert and end protection have been provided to the satisfaction of the Township in accordance with the Township's Road Occupancy Permit. (v) The trees have been planted on the lot by the Developer in accordance with Clause 7.3. (vi) Any deficiencies on a Provisional Certificate of Occupancy has been complied with. It is agreed that a copy of Part 8 shall be delivered by the Developer to each and every builder obtaining a builder's permit or any prospective purchaser of the dwelling for any lot or part of a lot on the said plan. 8.6. OCCUPANCY LIQUIDATED DAMAGES Notwithstanding the above, if for any reason whatsoever, occupancy of any building occurs before the vital services listed in Clause 8.5 are installed to the home occupied, to the satisfaction of the Township Engineer then the Developer agrees to pay to the Township, liquidated damages in the amount of One Hundred Dollars ($100.00) per dwelling per day to cover the additional costs of administration, inspection and fire protection, etc. The liquidated damages to commence at and include the date of occupancy and end when the Developer obtains a certificate from the Township Engineer that the vital services are satisfactorily installed. If the Developer fails to pay to the Township monies owing under this clause within thirty (30) days of the date of the bill the money may be deducted from the cash deposit or Letter of Credit or other deposited security. 26 , . L , .. 9.4 PART - 9 MAINTENANCE AND ACCEPTANCE 9.1 FINAL ACCEPTANCE OF UNDERGROUND SERVICES On receipt of the Developer's request for a final inspection of the underground services, the Township Engineer will again inspect the work, and if satisfied, will recommend to the Township that the Certificate of Maintenance and Final Acceptance (Underground Services) be issued. It should be noted that the Certificate of Maintenance and Final Acceptance (Underground Services) can be applied for by the Developer two (2) years after the receipt of the Certificate of Substantial Completion and Acceptance (Underground Services). Notwithstanding, anything hereinafter set out, the Township shall not be obligated to assume the responsibility for and take over the subdivision services until fifty percent (50%) of the lots on the subdivision or stage of the subdivision have completed dwellings erected therein and the Final Certificate of Occupancy has been issued. The Developer shall be responsible for the normal operation, maintenance, and all repairs of the services in this case until the Township has assumed the responsibility of the services. 9.2 SUBSTANTIAL COMPLETION OF ABOVEGROUND SERVICES When all of the services have been completed including the surface lift of asphalt, in accordance with this Agreement or in a particular stage, the Township Engineer and Public Works Official shall make an inspection to ensure that the Township will accept the road system. The Township Engineer shall issue a Certificate of Substantial Completion and Acceptance (Aboveground Services) when the Works are accepted by the Township. This Certificate may contain a list of minor deficiencies which have to be corrected by the Developer but which are not considered of sufficient importance to delay the issuance of the Certificate and the acceptance of the services by the Township. The two (2) year maintenance period will commence when the Township Council approves the issuance of the Certificate. 9.3. MAINTENANCE OF WORKS The Developer will be responsible for the repair and maintenance of all the subdivision services for a period of two (2) years from the date the Township Council approves the Certificate of Substantial Completion and Acceptance. This shall be called the Maintenance Period. The maintenance shall include the maintaining and mowing of grass within the road allowances as well as the parkland area and detention pond on a regular basis. If the Township is requested to carry out this maintenance, the Developer shall pay all charges to the Township. If during this period, the Developer fails to carry out maintenance work within forty-eight (48) hours after receipt of a request from the Township, then the Township Engineer may, without further notice, undertake such maintenance work and the total cost of such work including engineering fees shall be borne by the Developer. If the Developer fails to pay the Township within thirty (30) days of the date of billing, then the money owing may be deducted from the cash deposit or Letter of Credit. During the maintenance period, ten percent (10%) of the original estimated cost of the works shall be retained by the Township. Towards the end of the maintenance period, the Developer shall make written request to the Township for a final inspection to be made and notwithstanding the two (2) year period noted above, the maintenance period will continue for the original two (2) years or for thirty (30) days after the receipt of the Developer's written request for a final inspection, whichever period of time is the greater. Notwithstanding, anything hereinafter set out, the Township shall not be obligated to assume the responsibility for and take over the subdivision services until fifty percent (50%) of the lots on the subdivision or stage of the subdivision have completed dwellings erected therein and Final Certificate of Occupancy has been issued. The Developer shall be responsible for the maintenance of the services in this case until the Township has assumed the responsibility of services. WINTER ROAD MAINTENANCE An exception to the liability of the Developer for all maintenance and repair of the services during the two (2) year maintenance period will be winter control which operation will be the Township's responsibility after the issuance of the Certificate of Substantial Completion and Acceptance (Above ground Services). Winter control shall include snow ploughing, sanding and any other winter maintenance operations. It is agreed by the Developer that the winter control operations shall not prejudice the Township's rights to enforce the maintenance provisions. Prior to the issuance of the Certificate of Substantial Completion and Acceptance (Above ground Services) however, the Developer shall be responsible for the winter control also. In the event that proper vehicular access or winter control is not provided by the Developer, the Township through its servants, contractors, or agents may provide without notice to the Developer. Such winter control shall be only carried out at times deemed to be an emergency by the Public Works Official. All costs of such work shall be paid by the Developer within thirty (30) days of the date of billing or otherwise may be deducted from the cash deposit or Letter of Credit. 27 .... \." - 9.5 The cost of such works to be at the following rates: Machinery and Equipment Labour Mixed Sand and Salt Payroll Burden - 41 % Administration - 7% G.S.T. - 7% $28.00 /hr $15.00 /hr $12.00 /m3 These rates may be adjusted by the Township from time to time. The Developer further agrees that any work done by the Township pursuant to this agreement before the roads are accepted by the Township shall not be deemed in any way to be an acceptance by the Township of the roads in the said subdivision upon which such work is done. The Developer acknowledges that the Township whilst providing winter control may damage or interfere with the works of the Developer and covenants that he will make no claims against the Township for such interference or damage, providing the work is carried out in a normal and reasonable manner. REPLACEMENT OF SURVEY BARS Prior to the final acceptance of the subdivision by the Township, the Developer agrees to supply a statement from an Ontario Land Surveyor approved by the Township that after the completion of the subdivision work, he has found or replaced all survey monuments and standard iron bars shown on the registered plan. The statement must be dated within two months of the date of acceptance. 9.6 FINAL ACCEPTANCE OF ABOVEGROUND SERVICES On receipt of the Developer's request for a final inspection of the Aboveground Services, the Township Engineer will again inspect the work and if satisfied will recommend to the Township that the Certificate of Maintenance and Final Acceptance be issued. Notwithstanding anything hereinafter set out, the Township shall not be obligated to assume the responsibility for and take over the subdivision services until fifty percent (50%) of the lots on the subdivision or stage of the subdivision have completed dwellings erected therein and the Final Certificate of Occupancy has been issued. The Developer shall be responsible for the maintenance of the services, in this case, until the Township has assumed the responsibility of the services. 9.7. RELEASE OF LAND . The Developer, when not in default of the Subdivision Agreement to provide the requisite public services to the lands, shall be entitled to an effective release in a form suitable for registration in the County Registry Office for each lot or block which is in conformity with the overall grading plan for the lands or such variance therefrom as has been approved by the Township Engineer. Every such release shall operate as a discharge of all levies hereunder by the Township in respect to each lot or block described in the release with the exception of the responsibility for drainage as outlined in Clause 9.8 and the completion and maintenance of the services. 9.8 DRAINAGE - RESPONSIBILITY OF DEVELOPER AND SUBSEQUENT OWNERS It is understood and agreed that the drainage of surface waters upon and from the said lands shall remain the sole responsibility of the Developer and the subsequent owners from time to time of the lots or blocks within the Plan of Subdivision. The Developer and subsequent owners or the lots or blocks within the Plan of Subdivision from time to time shall provide and maintain adequate drainage of surface waters across and from the said lands in accordance with the provisions of Section 7.16 of this Subdivision Agreement. The Developer agrees to provide a copy of this Section 9.8 and Section 7.16 to each and every prospective builder/prospective purchaser of a lot or block within the Plan of Subdivision. The Developer and the owner from time to time of any lot or block within the Plan of Subdivision upon which the Township elects to enter for the purpose of rectifYing the said work, hereby agrees to indemnifY and release the Township from and against all claims, demands, actions or causes of action whatsoever arising as a result of the Township or of its servants or agents entering upon the lands for the purpose of correcting drainage problems. The cost of such work will be for the account of the Developer and/or subsequent lot owner. Any invoices not paid within thirty (30) days after due date, shall be added to the tax roll and collected in a like manner as realty taxes as per section 326 of the Municipal Act. 28 ~ - 41 c, 10.1. 10.2 PART - 10 DEFAULT PROVISIONS DEF AUL T PROVISIONS Notwithstanding anything herein before contained in this Subdivision Agreement, when the Developer is deemed by the Township to be in default of this Agreement, the Township reserves the right to realize upon securities deposited by the Developer to recover costs incurred by the Township, in accordance with the provisions of Section 5.6 of this Subdivision Agreement, and/or to restrict or refuse issuance of building and/or occupancy pennits for lots or blocks within the Plan of Subdivision, until such time as the Developer is in full compliance with the provisions of this Subdivision Agreement. SUCCESSORS AND ASSIGNS This Agreement shall be binding upon and enure to the benefit of the parties hereto and their respective heirs, executors, administrators and assigns. 10.3 SUBSTITUTION FOR APPROVALS Wherein this agreement reference is made to any named Ministry of the Province or other public body, such reference where the same requires their approval is deemed to be a reference to any other Ministry or body as may be substituted by legislative change or policy of the Provincial Government. IN WITNESS WHEREOF the parties hereto have executed this Agreement and have hereunto caused to be affixed the corporate seals, duly attested to by the proper signing officers. 1999. SIGNED, SEALED AND DELIVERED this THE CORPORATION OF THE TOWNSHIP OF ORO-MEDONTE Per Title Per Title 29 , - ~ '. SCHEDULE "A" NOTE: It is understood and agreed that this Schedule forms part of the Subdivision Agreement between the Township ofOro-Medonte and 1091402 ONTARIO LTD. DESCRIPTION OF LANDS AFFECTED BY THIS AGREEMENT: ALL AND SINGULAR, that certain parcel or tract of premises, situate, lying, and being in the Township of Oro-Medonte (formerly Township of Oro), in the County of Simcoe, and being composed of the whole of the lands described as follows: PART OF LOT 37, CONCESSION 1, EAST OF PENETANGUISHENE ROAD RP 51R-23604 30 e ~ SCHEDULE "B" NOTE: It is understood and agreed that this Schedule forms part of the Subdivision Agreement between the Township of Oro-Medonte and 1 091402 ONTARIO LTD. PLAN OF SUBDIVISION 31 e ~ " NOTE: SCHEDULE "C" It is understood and agreed that this Schedule forms part of the Subdivision Agreement between the Township ofOro-Medonte and 1091402 ONTARIO LTD. WORKS TO BE CONSTRUCTED Complete roadway construction including excavation, granular roadbed materials, curb and gutter where required, two lifts of asphalt, topsoil and seeded boulevards with sod and erosion control measures as required; Storm drainage works including ditches, culverts, storm sewer and detention pond; Street and traffic signs; Underground hydro, telephone, gas and street lighting; Parkland All of the above works are incorporated on to the following engineering drawings prepared by Vincent & Associates, Project No. 91508-20, Municipal Affairs No. 43T -90055. C.C. Tatham & Associates Ltd. are the new developer's Engineers for the supervision of the construction of the works. The above referenced drawings were stamped as accepted by the Township Engineers, R.G. Robinson and Associates (Barrie) Ltd., on October 29, 1993. Drawill2 No. G-l to G-4 S WD-l LG-l to LG-3 P-l to P-2 P-3 to P-4 P-5 to P-7 P-8 to P-9 P-lO P-ll P-12 SD-l to SD-3 PND-l PND-2 PND-3 PND-4 Description General Servicing Plan Storm Drainage Plan Lot Grading Plan Plan and Profile - Green Mountain Court Plan and Profile - Pineview Drive Plan and Profile - Northwood Court Plan and Profile - Red Pine Court Plan and Profile - Maplehill Drive Plan and Profile - Block 77 and 76 Plan and Profile - Woodland Crescent and Block 67 Standard Detail Sheet Extended Detention Facility Basin 100-Block 78 Extended Detention Facility Basin 200-Block 73 Extended Detention Facility Basin 300-Block 79 Pond Section 32 SCHEDULE"D" NOTE: It is understood and agreed that this Schedule forms part of the Subdivision Agreement between the Township ofOro-Medonte and 1091402 ONTARIO LTD. ITEMIZED ESTIMATE OF COST OF CONSTRUCTION OF EACH PART OF THE WORKS The following list summarizes the cost estimate of the major works but is not necessarily inclusive: e PHASE 1 - INTERNAL WORKS (Lots 1-11 and 34-56) A) Roadway construction complete including clearing and grubbing, excavation, granular road base materials and two lifts of asphalt............................................................$ 286,523. B) Storm Drainage works complete including storm sewers, ditch inlet catchbasins, culverts, detention pond, topsoil, seed and mulch, sod, ditching and siltation and erosion control devices... ....... ............... .......... ... ... ... ... ... ... ... .... ... .....$ 288,853. C) Miscellaneous Items such as street name and regulatory signs..................................... ..................... ... ......... ...$ 37,237. D) Electrical Supply including street lights, control panels and duct crossings..................................... ........................ $ 27,027. E) Parkland works including grading, trees, fence and park sign ..... .............. ... ... ... ... .... ................. .................. $ 2,500. F) Allowance for Engineering and supervision. ............................................. $ 67,214. G) Allowance for Fire Water Reservoir...... ... ...... ......... ......... ......... ....$ 30,000. 7% G.S.T. $ 739,354. $ 51,755. SUB-TOTAL H) Final Occupancy & Lot Grading Deposit (33 lots X $2,000./lot)... ......... ...... ... .................. ......... .... $ 66,000. Lot 36 is complete TOTAL PHASE I - INTERNAL WORKS $ 857,109. PHASE I - EXTERNAL WORKS (Connecting Roads through Maplehill II) A) Roadway Construction complete, including clearing and Grubbing, excavation, granular road base materials and Two lifts of asphalt... ... ........................... ...... ..................... ..... $ 97,504. B) Storm Drainage Works complete, including storm sewer, ditch Inlet catchbasin, culverts, detention pond, top soil, seed and Mulch, sold, ditching and siltation erosion control devices......... $ 39,430. E) Parkland.................. ......... ...... ......... ...... ........................... ... 4,420. $ 12,718. $ 0 C) Miscellaneous Items such as Street Name and Regulatory Signs............. $ D) Electrical Supply including Street Lights, Control Panels and Duct Cross ings .. . . .. . . . .. . . .. .. . .. . .. . . . . . . . . . . . .. . . . .. . .. . . .. . . . . .. . .. . .. .. . .. . . .. . 4, F) SUB-TOTAL - PHASE 1 - EXTERNAL WORKS $ 15,407. $ 169,479. $ 11,864. $ 181,343. $1,038,452. Allowance for Engineering & Supervision (10%) ... ... ... ... ... ... ... 7% G.S.T. TOTAL PHASE I - EXTERNAL WORKS GRAND TOTAL - PHASE I 33 B) e C) D) E) F) PHASE 2 (Lots 12-33 and 57-65) A) Roadway construction complete including clearing and grubbing, excavation, granular road base materials and two lifts of asphalt............................................................$ 191,563. Storm Drainage works complete including storm sewers, ditch inlet catchbasins, culverts, detention pond, topsoil, seed and mulch, sod, ditching and siltation and erosion control devices...................................... ... ... ......... .......... .....$ 389,246. Miscellaneous Items such as street name and regulatory signs...................... ...... ............... ... .,. ............ ......... ...$ 50,855. Electrical Supply including street lights, control panels and duct crossings..................................... ........................ $ 71,600. Parkland works including grading, trees, fence and park sign ............................ '" .... '" ......... ..... ... ... ...... ...... $ 2,500. Allowance for Engineering and supervision. ............................................. $ 70,576. SUB-TOTAL PHASE 2 $ 776,340. $ 54,344. 7% G.S.T. G) FINAL OCCUPANCY AND LOT GRADING DEPOSIT (32 Lots X $3,000/Lot) TOTAL PHASE 2 . $ 64,000. $ 894,684. 34 , . '" NOTE: SCHEDULE "E" It is understood and agreed that this Schedule forms part of the Subdivision Agreement between the Township ofOro-Medonte and 1091402 ONTARIO LTD. LIST OF LOTS UNSUITABLE FOR BUILDING PURPOSES & LIST OF LOTS REQUIRING SPECIAL ATTENTION See Clause 8.1 which sets out specific requirements for all lots on the Plan in order to obtain a building permit for each and every lot. 35 . .. , . .. "' SCHEDULE "F' SERVICES-IN-LIEU AGREEMENT (pursuant to Section 9 of the Development Charges Act) This Agreement made as of this day of October, 1997 BETWEEN: 1091402 ONTARIO LTD. (hereinafter referred to as the "Developer") Party of the First Part -and- THE CORPORATION OF THE TOWNSHIP OF ORO-MEDONTE (hereinafter referred to as the "Township") Party of the Second Part WHEREAS the lands affected by this agreement are the lands described in Schedule "A" annexed hereto and are also shown on the Plan of Subdivision attached to and forming part of this agreement as Schedule "B" (collectively are hereinafter referred to as the "Lands"); AND WHEREAS a draft plan with conditions know as 43- T -90055 has been approved for the proposed subdivision of the Lands; AND WHEREAS the Township has enacted By-law 91-91 as amended pursuant to the provisions of the Development Charges Act, RS.O. 1990, c. D.9, which is applicable to the Lands; AND WHEREAS Section 9(9) of the Development Charges Act provides that a municipality may, by agreement, permit an owner to provide services-in-lieu of the payment of all or any portion of a development charge; AND WHEREAS the Township has agreed to allow a credit from development charges payable pursuant to By-law 91-91 as amended in return for the provision of certain transportation facilities or the funding thereof; NOW THEREFORE this agreement witnesseth that in consideration of the premises and for other good and valuable consideration and for the sum of $2,00 (two dollars) of lawful money paid by the Developer to the Township (the receipt and sufficiency of is hereby acknowledged), the Developer and the Township hereby covenant and agree with one another as follows: 1 Payment of Development Chaf2es 1.1 The Developer agrees to pay development charges in accordance with By-law 91-91, as amended of the former Corporation of the Township of Oro or in accordance with any subsequent by-laws or amendments thereto enacted by the Township pursuant to the Development Charges Act or the Development Charges Act, 1997 (Government Bill 98) (hereinafter referred to as the "Development Charges"). 1.2 Development charges are payable prior to the issuance of building permits, except that portion of the development charge that relates to water supply services, sanitary sewer services, storm and drainage services, transportation services and electrical power or energy services (the "Bard Service Charge"), which shall be paid in full upon the execution of a subdivisio)). agreement. 36 t . \ 2 Credits from the Payment of Development Chan?:es 2.1 (1) The Developer shall be credited ftom the payment of the Development Charges as set out in Section 1 above for its costs for the provision or funding of the following works and facilities: (a) Construction ofa portion of Bidwell Road (the "Bidwell Works"), being of approximately 780m of a rural cross-section including granule subbases, base course, asphalt, ditching and top soil, seed and mulch on boulevards, as more particularly shown and detailed on RG. Robinson & Associates Limited drawing P-4, P-S, P-6 and P-7, Job 012-92083-20, dated December 14, 1992, attached hereto as Schedule "C". (b) The Developer agrees to commence construction of the Bidwell Works on or about October 6, 1997, and to complete construction on or about November IS, 1997. (c) The total value of construction of the Bidwell Works IS estimated as $119,046.00. (2) The development charge credit is to commence upon completion of the Bidwell Works to the satisfaction of the Township or the posting of a letter of credit in the amount of $119,046.00 to the satisfaction of the Township in the form attached hereto as Scheduled "D", whichever event occurs first and is to be first applied to the Hard Service Charge, which is established as $72,996.00, and then on a pro rata basis, having regard to the number of building permits remaining to be issued according to the following: (a) The total of the credit is to be, in the event a letter of credit is posted, the estimated cost established in Subsection 2.1 (1)( c) above, or in the event that the work is completed and no letter of credit is provided, the actual cost of the Bidwell Works which shall be confIrmed immediately upon completion by the Owner's engineer, who shall provide supporting documentation to the Town's engineer if so requested. In the event of disagreement between the Owner's engineer and the Town's engineer regarding the actual cost of the Bidwell Works, the opinion of the Town's engineer shall prevail. (b) The total amount of the credit, less the value of any credit applied to the Hard Service Charge (estimated as $72,996.00), is to be divided by the number of building permits outstanding to yield the per unit credit. (c) The payment of the development charge is the amount of the development charge per dwelling unit applicable at the time of the issuance of the building permit, minus the per unit credit. If the total credit exceeds the amount of the development charge payable to the Town, the credit shall not be applicable against any other charges or levies and the credit shall be at an end, except with respect to any further phases of the subdivision of the Lands, in which case this provision of this agreement shall apply mastitis mutandis. (d) If the credit is calculated on the basis that a letter of credit is provided, the actual cost of the works and facilities for which the credit is subject shall be confirmed immediately upon completion whereby the Owner's engineer shall supply supporting documentation to the Town's engineer if so requested. Any discrepancy between the estimated cost set out in Subsection 2.1(1)(c) above and the final cost shall be included in the calculation of subsequent credits. If all building permits have been issued or all credits exhausted, the Town or the Owner shall reimburse one to the other as necessary to ensure that the quantum of the credit is based upon the actual cost of the construction. 37 (e) In the event that the Bidwell Works have not been completed as required in Subsection 2.1 (1 )(b) are deficient or defective or not being proceeded with expeditiously, the Town may, at its sole discretion draw-down upon the letter of credit referred to in Subsection 2.1(2) above for the purposes of commencing, completing or repairing work and, in the event that letter of credit security is, for any reason, insufficient to compensate the Township for the cost of such construction or remedial work, the difference shall become immediately due and payable as development charges and the Township may, in addition to any other remedies at law, require, in its sole discretion, such payment in full prior to the issuance of any further building permits. In the alternative, the Township may, in its sole discretion, draw- down upon the letter of credit and apply such monies against the payment of development charges for which building permits have been issued or are to be issued to which the credit would have otherwise applied. t (f) The letter of credit referred to in Subsection 2.1(2) above shall be returned subject to a hold back of 10% for maintenance for a period of 1 year following completion to the satisfaction of the Town of the Bidwell Works. (3) The Bidwell Works shall be deemed to be "Works" required by any Subdivision Agreement between the Township and the Developer which provisions shall apply where appropriate to the Bidwell Works. (4) In the event that the credit has not commenced prior to the execution of the subdivision agreement, the Developer shall pay the full amount of the hard services charge, either by cash or by letter of credit, which shall be returned or refunded upon the commencement of the credit as set out in subsection 2.1(2) above. 3 Jurisdiction and Estoppel 3.1 The parties agree that they have the jurisdiction and authority to enter into this agreement and that they are forever estopped nom challenging the validity of this agreement or any of its provisions before the Courts of Ontario, any administrative tribunal or other authority having jurisdiction to rescind, vary or amend the provisions of this agreement without the concurrence of all parties. 4 Severability and Further Assurances 4.1 In the event that a court quashes any portion of this agreement or declares any portion of this agreement to be null or unenforceable such provision(s) shall be severed nom the remainder of this agreement which shall continue in full force and effect. The parties agree to execute such further assurances as may be necessary to carry into effect the provision(s) quashed or declared to be null or unenforceable. 5 Law of Ontario 5.1 This agreement shall be construed and enforced in accordance with the laws of the Province of Ontario and the laws of Canada applicable therein and shall be treated in all respects as an Ontario contract. . 38 , . 6 Entire Au:reement 6.1 This agreement and any agreements herein contemplated or referred to be entered into between the parties hereto constitute the entire agreement between the parties hereto pertaining to the subject matter hereof and supersede all prior agreements, understandings, negotiations and discussions whether oral or written of the parties hereto and there are no warranties, representations or other agreements between the parties in connection with the subject matter hereof, except as specifically set forth herein. 6.2 No supplement, modification or waiver or termination of this agreement shall be binding unless executed in writing by the parties hereto. 39 e . 6.2 No supplement, modification or waiver or termination of this agreement shall be binding unless executed in writing by the parties hereto. 7 Nonwaiver 7.1 No waiver of any of the provisions of this agreement shall be deemed or shall constitute a waiver of any other provisions (whether or not similar), nor shall such waiver constitute a continuing waiver. Failure on the part of party to complain of any act or failure to act of another party or to declare another party in default in respect of how long such failure continues, shall not constitute a waiver by such first mentioned party of its rights hereunder. 8 Currency 8.1 All amounts stated herein are stated in Canadian currency. 9 Enurement 9.1 All the terms and provisions of this agreement shall be binding upon the parties hereto and their respective successors and assigns. 10 Effective Date 10.1 The parties agree that this agreement and any provision hereof shall become effective upon execution. IN WITNESS WHEREOF the parties hereto have executed this Agreement and have hereunder caused the affix of the corporate seals, do and attested to by the proper signing officer. SIGNED, SEALED AND DELIVERED this 3/ day of October, 1997 1091402 ONTARIO LTD. Per: ~i ~([,_" h /:t:- Title: E.J7e,'~,,-lt/ H~lf). Per: Title: THE CORPORATION OF THE TOWNSHIP OF ORO-MEDONTE . ./ / /( Per: -z~~ /l~ Clerk Per: ('~_ Mayor 1 Ac~, ""/ / 40 , . SCHEDULE"G" NOTE: It is understood and agreed that this Schedule forms part of the Subdivision Agreement between the Township of Oro-Medonte and 1091402 ONTARIO LTD. Cash Deposits, Development Charges and Securities The Developer, as a capital contribution towards other Township services, will pay to the Township in addition to all other monies required to be paid by the Developer under this Agreement the Development Charges, in an amount required by the Township's Development Charges By-Law on the date the payment is received by the Township at the Municipal Office. The Development Charges in place at the time of the execution of this Agreement is Two Thousand Nine Hundred and Sixty ($2,960.00) per dwelling unit. An amount equal to or greater than the hard services portion of the total Development Charges for all the lots must be paid at the time of execution of the Subdivision Agreement. Prior to issuance of a building permit the remainder of the Development Charges is to be paid on a per lot basis, until levies have been paid for all lots. Development Charges Breakdown PHASE 1- 34 Lots Total Development Charges Due - Phase I 33 lots at $2,960.00, Lot 36 completed $97,680.00 Prepayment for Hard Services Portion of Levies 33 lots at 43.9% of $$2,960.00, less credit of : = Equivalent hard services portion of levy for lots due $(42,867.00) $ O.OO/Iot Remainder of Levies Due Prior to Issuance of Building Permits 33 lots at 56.1 % of $2,960.00 Lot 36 completed Total Pre Service Agreement Credit $54,813.00 ($124,201.11 ) Phase I Hard Services Portion Credit Phase II Hard Services Portion Credit Total Credit - Hard Services Portion ($ 42,867.00) ($ 41,568.00) ($ 84,435.00) Remainder of Levies Due Prior to Issuance of Building Permits Equivalent remainder of levy for lots = $ 15,046.89 $ 455.97/lot PHASE 2 - 32 Lots Total Levies Due - Phase 2 32 lots at $2,960.00 $ 53,152.00 Prepayment for Hard Services Portion of Levies 32 lots at 43.9% of $2,960.00 Equivalent hard services portion of levy for lots due $(41,568.00) $ O.OO/Iot Remainder of Levies Due Prior to Issuance of Building Permits 32 lots at 56.1 % of $2,960.00 Equivalent remainder of levy for lots Total Development Charges Payable = $ 53,152.00 $ 1,661.00/10t $ 68,~98.89 41 , . Note: 1) The hard services portion oflevy (43.9%) was derived from Table C-2 of Township ofOro's Development Charge Policy Report. 2) This breakdown is based on the current levy. 3) The credit is based on the provision of services-in-lieu set out in Schedule "F", totalling $124,20 l.ll. 42 , ~ . SCHEDULE"H" NOTE: It is understood and agreed that this Schedule forms part of the Subdivision Agreement between the Township ofOro-Medonte and 1090402 ONTARIO LTD. DEEDS AND EASEMENTS TO BE CONVEYED All title documents shall be properly drawn and executed by the parties, with the appropriate Lot or Block Number inserted in the description of the document, and the registered Plan Number shall be left blank, to be inserted by the solicitors for the parties after the Plan is registered and a Plan Number assigned. The consideration for all conveyances shall be the sum of Two Dollars ($2.00) and the cost of preparation, execution and registration thereof, shall be borne by the Developer. All documents to be registered, shall be prior approved by the Solicitor for the Township. The following land and easement shall be conveyed: 1.0 LANDS TO BE CONVEYED TO THE TOWNSHIP BLOCKS 69, 70, 71, 72, 74, 75 (For Walkways) BLOCK 67 & 77 (For Walkways and Drainage) BLOCK 68 & 76 (For Open Space) BLOCKS 73, 78 & 79 (For Storm Management) Block 80 (For 0.3 Metre Reserve) 2.0 DRAINAGE EASEMENTS TO BE CONVEYED TO THE TOWNSHIP NONE 43 - t NOTE: PARKLAND SCHEDULE "I" It is understood and agreed that this Schedule forms part of the Subdivision Agreement between the Township ofOro-Medonte and 1090402 ONTARIO LTD. BLOCK 68 AND BLOCK 76 TO BE LEFT IN A NATURAL CONDITION 44 e t - '. SCHEDULE "J" TOWNSHIP OF ORO-MEDONTE DECLARATION OF PROGRESS AND COMPLETION SUBDIVISION: MAPLEHILL ESTATES DEVELOPER: 1091402 ONTARIO LTD. CONSULTING ENGINEER: C.C. TATHAM & ASSOCIATES LTD. As required by the Agreement between the Corporation of the Township ofOro-Medonte and 1090402 ONTARIO LTD. The Developer( s) dated 1. The Developer hereby agrees and undertakes to complete the construction of the Works as required by the above-mentioned agreement in accordance with the time schedule for the completion of services as approved by the Township Engineer and more specifically in accordance with the following schedule and conditions: a) Before any building erected on the lots or blocks in the Plan are occupied all the Requirements for Occupancy as set out in Clause 8.5 shall be complied with. b) Granular "B" and Granular "A" on or before c) Grading, topsoiling and seeding of private blocks and parks on or before d) Boulevard sodding on all roads on or before e) Hot asphalt on or before 1) Planting of trees on or before 2. The Developer further agrees that the Township is hereby authorized to carry out, at his expense, any of the work set out in this Declaration not finished on or before the completion dates, to be commenced not sooner than one week following such completion date, it being understood and agreed that the Township's authorization is limited only to that work required under the Declaration. 3. The Developer undertakes to properly maintain the gravel road base at all times and to keep all roads in a mud-free and dust-free condition until such times as the roads, including boulevards, have been completed. 4. The Developer further agrees and the Township is hereby authorized to undertake any of the maintenance work as set out under Item 3 hereof, not completed by him within 24 hours after receipt of such request for maintenance, at his expense, and without limiting the generality of the foregoing, the Township's cost shall be the cost of materials, equipment rental, labour, payroll burden, plus 20% for overhead. 45 e t I' 5. It is understood and agreed that should the Developer fail to construct the remaining services to carry out the requirements of Item 3 as stipulated, and by such dates and within such time limits as provided by this undertaking the Developer notwithstanding the costs noted in Section 4, shall pay to the Township, as predetermined liquidated damages, the sum of fifty Dollars ($50.00) for each and every calendar day the said services are behind schedule of construction provided such delay is not caused by strikes or acts of God or additional work being requir~d by the Township. Seal or Witness Signed - e SCHEDULE "K" NOTE: It is understood and agreed that this Schedule forms part of the Subdivision Agreement between the Township ofOro-Medonte and 1090402 ONTARIO LTD. GENERAL LOCA nON AND LOT GRADING PLANS PROCEDURE After the General Location and Lot Grading Plan have been approved by the Township, then: a) six copies to be delivered to the Solicitor for the Township; b) six copies to be delivered to the Township; c) mylars for each Plan incorporated into the Subdivision Agreement shall be delivered to the Solicitor for the Township. 47 e e " ~ SCHEDULE "L" SUBDIVISION AGREEMENT - STANDARD FOR THE TOWNSHIP "STANDBY" LETTER OF CREDIT IRREVOCABLE LETTER OF CREDIT DATE OF ISSUE: NAME OF BANK: ADDRESS OF BANK: LETTER OF CREDIT NO.: AMOUNT: $ Except as otherwise expressly stated, this Letter of Credit is issued subject to the Uniform Customs and Practices for Documentary Credits (1993 Revision), being ICC Publication No. UCP 500. TO: THE CORPORATION OF THE TOWNSHIP OF ORO-MEDONTE P.O. Box 100, Oro Ontario, LOL 2XO We hereby authorize you to draw on the Bank of Ontario, . for the account of , up to an aggregate amount of whiCh IS aVailable on demand. , , ($$$$$$$$) Pursuant to the request of our said customer, , we, the Bank of , , Ontario, , hereby establish and give to you an irrevocable Letter ot Credit In your tavour, in the above amount, WhICh may be drawn on by you at any time and from time to time, upon written demand for payment made upon us by you which demand we shall honour without enquiring whether you have the right as between yourself and our said customer to make such demand and without recognizing any claim of our said customer or objection by them to payment by us. Demand shall be by way of a letter signed by an authorized signing officer of the Corporation of the Township ofOro-Medonte. The original Letter of Credit must be presented to us at : Bank of , , Ontario, . The Letter of Credit, we understand, relates to a SubdivIsion Agreement between our said customer and the Corporation of the Township ofOro-Medonte, with Mortgage Company, as a third party, regarding subdivision of (property description) The amount of this Letter of Credit may be reduced from time to time, as advised by notice in writing, given to us by an authorized signing officer of the Corporation of the Township of Oro-Medonte. Partial drawings shall be permitted. We hereby agree that partial drawings under this Letter of Credit will be duly honoured upon demand. This Letter of Credit will continue in force for a period of one year, but shall be subject to the condition hereinafter set forth. It is a condition of this Letter of Credit that it shall be deemed to be automatically extended without amendment from year to year, from the present or any future expiration date hereof, unless at least thirty (30) days prior to the present, or any future expiration date, we notify you in writing by registered mail that we elect not to consider this Letter of Credit to be renewable for any additional period. Dated at , Ontario, this day of 19 authorized signature authorized signlin~rf3 Bank of 48 .. ,: e e SCHEDULE "M" THE CORPORATION OF THE TOWNSHIP OF ORO-MEDONTE BY-LAW NO. 97- 9 9 Being a By-law to Authorize the Execution of an Agreement for Shared Road Access between Huronia Homes Ltd. And 1091402 Ontario Ltd. V"'HEREAS draft approval for a registered plan of subdivision on Part of Lot 37, Concession 1, Township of Oro-Medonte, County of Simcoe (Oro), known as the Maplehill Estates Subdivision has been obtained from the .Mlnistry ofl\funicipal Affairs and Housing; AND WHEREAS draft approval for a registered plan of subdivision on Part of the East HaIf of Lot 36, Concession 1, Township of Oro-Medonte, County of Simcoe (Oro), known as the Huronia Homes Ltd. Subdivision has been obtained from the Ministry of Municipal Affairs and Housing; AND WHEREAS 1091402 Ontario Ltd. Is desirous of developing its lands and requires access over the roads to be cut through the lands owned by Huronia Homes Ltd., in trust; A1'ID WHEREAS Huronia Homes Ltd., in trust, is willing to allow 1091402 Ontario Ltd. To enter upon its lands on the roads that have been designated to be cut through thereon for the development of its lands as set out above; NOW THEREFORE THE COUNCIL OF THE CORPORATION OF THE TOWNSHIP OF ORO-MEDONTE ENACTS AS FOLWWS: 1. That the Mayor and Clerk are hereby authorized to execute on behalf of the Corporation of the Township of Oro-Medonte a Shared Access Agreement dated November 12, 1997, a copy of which is attached hereto and forms part of this By-law as Schedule "AT'. BY-LAW READ A FIRST AND SECOND TIME, THISl9TH DAY OF NOVE1\mER, 1997. BY-LA\V READ A THIRD TIME AND FINALLY PASSED THIS 19 TH DAY OF NOVEMBER, 1997. THE CORPORATION OF THE TOWNSHIP OF ORO- MEDONTE 7 )1 ";" / / ,<,' ( I.. -f.!',- /C.,) "."'-':1::.,,'..... J:. ' Mayor - Ian Beard J . ' 4~~ li;{'- Clerk - Lynda Aiken "i.' \ ' ~ . .. THIS INDENTURE OF AGREEMENT dated the 11.d.'dayof November, 1997, MADE BETWEEN: HURONIA HOMES LTD., in trust, of the First Part; - and - 1091402 ONTARIO LTD. of the Second Part; THE CORPORA nON OF THE TOWNSHIP OF ORO-MEDONTE of the Third Part. WHEREAS Huronia Homes Ltd., in trust, is the owner of lands described as Part of the East Half of Lot 36, Concession 1, being designated as Part 3 & 8, on Reference Plan 5lR-16674, Township ofOro-Medonte, County of Simcoe; AND WHEREAS 1091402 Ontario Ltd. is the owner of lands described as Parcel 37-1, in the Register for Section 5l-0ro-l, being Part of Lot 37, Concession 1, E.P.R., Township ofOro, County of Simcoe, being part 1 on Reference Plan 51R-23604; AND WHEREAS 1091402 is desirous of developing its lands and requires access over the roads to be cut through the lands owned by Huronia Homes Ltd., in trust; AND WHEREAS Huronia Homes Ltd., in trust, is willing to allow 1091402 Ontario Ltd. to enter upon its lands on the roads that have been designated to be cut through thereon for the development of its lands as set out above; WITNESSETH THAT in consideration of the sum of FIVE DOLLARS ($5.00) and other good and valuable consideration, the receipt of which is hereby acknowledged by Huronia Homes Ltd., in trust, Huronia Homes Ltd., in trust does hereby grant to 1091402 Ontario Ltd. the right of access and egress over the roads presently located through the lands owned by Huronia Homes Ltd., in trust, for the development of the lands owned by 1091402 Ontario Ltd. Huronia Homes Ltd., in trust, shall convey to the Corporation of the Township ofOro- Medonte, in fee simple, without encumbrances, the lands described as Part of the East Half of Lot 36, Concession 1, being designated as Parts 3 and 8 on Reference Plan 5lR- yI..:tI. 16674, Township ofOro-Medonte, County of Simcoe, sRecifis:ally, those lands upon /. ~ which there are located two access roads, running from Rb't~t~n Road, as shown in L...--./U Schedule "A" attached hereto, within 30 days of a written request provided by The Corporation of the Township ofOro-Medonte. 1091402 shall save and hold harmless The Corporation of the Township ofOro-Medonte from any claims, actions or proceedings arising from or in relation to use and ownership of the two access roads described above. The Township makes no representation or commitment that it shall at any time acquire the roadway lands for the purposes of a public highway or to permit access into the lands of 1091402 Ontario Ltd.; ,) , , . ~ & ., Huronia Homes Ltd., in trust, and 1091402 Ontario Ltd. shall permit The Corporation of the Township of Oro- Medonte and its agents access and egress over the roadway lands for the purposes of inspection, construction, rectification, and maintenance, if required, of the roadway lands and to permit access into the lands of 1091402 Ontario Ltd. for the aforementioned purposes. HOMES LTD., in trust Per: Luigi Orsi, A. 1091402 ONTARIO LTD. Per: /~,~././~ ~. THE CORPORA nON OF THE TOWNSHIP OF ORO-MEDONTE Per: t.i,~- l1'co_._IJ / Per: ~- dL ....., ., . ,- ,~ . t:;.,.~_"" --"- - - I I 9 11 0 /11 I I 14 15 66 -QcR(Sc8'l} '~lL__ 36 ----------- \ ~, \ ",~ W ~'>''- Q9 ~ " "~---' --. - ------ - PHASE 1A - LOTS 1 TO 7 AND LOT 36 =8 PHASE 1B - LOTS 8 TO 11, 34 & 35 AND 37 TO 56 =26 PHASE 2 - LOTS 12 TO 33 AND 57 To]K65 -32 66 LOTS TOTAl . c.c. TATHAM It ASSOCIATES LID. ConsuIIIng EngineIn jF)1J=IIffi\~@{I~ ~1Lt4\IM IiIiAPI.BB.L IESTATES TOWNSHIP h -MEDONTE SCALE: 1: 5000 DWG. No. IP>lHJlP>iL JOB NO. 97122 . ~ Province of O",",m Ontario Document General Fonn 4 - Land Registration Re'onn Act, 1984 o '11/; , ~'1' " >- ...J Z o C8 C',J ( ,." 1""'"",\ (": C'~ ~.Li New Property::.RIentifiers Additior'ial: See 0 Schedule Executions Additional: See Schedule (8) This Document provides as 'ollows: Site Plan Agreement as attached. (1) Registry iJ (3) Property Identl'ler(s) Land Titles ~ (2) Page 1 of 53 pages Block Property Additional: See 0 Schedule (4) Nature 0' Document Vh4-j't( d1 Site Plan Agreemeht! under the Planning Act. (5) Consideration ) of Dollars $ nla (6) Description All that Part of f...Dt 37, Concession 1, East Penetan~Jishene Road, Reference Plan 51R-23604, Township of Oro-Medonte (formerly Township of Oro), County of Simcoe D (7) This Document Contains: o (a) Redescription New Easement Plan/Sketch (b) Schedule for: Description 0 Additional Parties 0 Other [X] (9) This Document relates to Instrument number(s) (10) Party(les) (Set out Status or Interest) Name(s) THE CORPORATION OF THE 'I'QIJ\j]\TSHIP Continued on Schedule 0 Signature(s) Date of Signature 'r M 0 , . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 1999 103 ! 11 . . ^ . . : . . 0:' . . ! : , . I : . . . . . ! . . 'J' . . I : I I , I . . . . . j . . .!. . . . . . . . . . . . . . . . . .QI: .QR.Q-.t-1E.~~~." )Jy. ?-~? C;:~-~~~! .~JYr:~~ .~~]~~r: .. . . . " . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . ~11.J11:tc:j~p'~],i.ty. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . I have the authority to bind the Corporation. (11) Address 'or Service . .. . . . . . . . . . . . .. ....... ... Oro, Ontario LOI. 2XO P.O. Box 100, (12) Party(les) (Set out Status or Interest) Name(s) 1091402 O~ITARIO LTD. Signature(s) Date of Signature Y M 0 . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .. .................................. OWner . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .. .................................. ..... .. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .. .................................. ..... .. ... (13) Address for Service (14) Municipal Address of Property Not Assigned (15) Document Prepared by: Lynda Aiken Clerk, Tswp. of Oro-Medonte P.O. Box 100 Oro, Ontario LOL 2XO I Fees and Tax ~ 5 Registration Fee w CI) ::> w S::!i u.. u.. o a: f2 Total I